1
REPORTABLE
IN THE SUPREME COURT OF INDIA
CIVIL APPELLATE JURISDICTION
Civil Appeal No. 6239 of 2019
Wg. Cdr. Arifur Rahman Khan ...Appellants
and Aleya Sultana and Ors.
Versus
DLF Southern Homes Pvt Ltd ...Respondents
(now Known as BEGUR OMR Homes Pvt. Ltd.) and Ors.
With
Civil Appeal No. 6303 of 2019
2
J U D G M E N T
Dr. Dhananjaya Y. Chandrachud, J
1 The National Consumer Disputes Redressal Commission1
dismissed a
consumer complaint filed by 339 flat buyers, accepting the defence of DLF
Southern Homes Pvt. Ltd. and Annabel Builders and Developers Pvt. Ltd. that
there was no deficiency of service on their part in complying with their contractual
obligations and, that despite a delay in handing over the possession of the
residential flats, the purchasers were not entitled to compensation in excess of
what was stipulated in the Apartment Buyers Agreement2
.
2 The complaint before the NCDRC was initially instituted by nine flat
buyers. These nine complainants had booked residential flats in a project called
Westend Heights at New Town, DLF, BTM Extension at Begu, Bengaluru. The
project was being developed in an area admeasuring 27.5 acres and was to
consist of 1980 units, spread across nineteen towers each consisting of a stilt
and eighteen floors.
3 The Brochure of the first respondent advertised the nature of the project
and the amenities which would be provided to buyers. It held out the following
representations on the basis of which buyers were induced to invest:
1
“NCDRC”
2
“ABA”
3
“New Town - the premier choice for Bangalore living. A
premium residential enclave that celebrates life in all its
resident splendor. Featuring spacious apartments and a rich
selection of amenities, you will find in New Town, a
residence specially appointed to maximize your comfort
and convenience. In New Town premium high rise
apartments are set against the backdrop of a vibrant living
environment where fun, comfort, security, and serenity blend
in perfect unison. Life at New Town satisfies all your needs
and fulfils your heart's desire. Imagine a place where
leisurely pursuits are always within reach. Imagine living
where convenience is never more than around the
corner.
Westend Heights at New Tower DLF, BTM Extn.
Designs, keeping in mind the modern day requirements
and meeting them with apt amenities, Westend Heights is
the first phase of New Town, with premium high-rise
apartments at affordable prices. The complex brings you
comfort living embodied in individual towers overlooking
sprawling parks and vistas. This project is being developed in
a land area of 27. 5 acres. The project consists of 1980 units
spread across 19 towers that are Stilt+ 18 floors high.
Amenities
Fun, Fitness, Leisure, Right Next Door
The most exclusive Club in Bangalore at New town, DLF
BTM, EXTN,
The Club set amidst a very comfortable setting is an
impressive feature of New Town. It is specially designed to
take care of all stresses brought on by the modern world.
Altogether a beautiful composition, that blends seamlessly
with your lifestyle.
Swimming Pool:
Gymnasium/ Aerobics Centre
Restaurant & Bar
4
Billiards Room
Banquet Hall
Tennis Courts
Cards Room
Squash Courts
Spa, Massage & Beauty Parlour
Ease, Enjoyment, Convenience. Right Next Door
Convenient shopping facilities at New Town, DLF BTM
EXTN
Shop with ease at our convenience shopping centre, well
equipped to handle your everyday needs. The shopping
centre will offer an array of outlets to make your life a
trouble free affair.
Experience convenience at your doorstep
Hope, Dreams, Future. Right Next Door
Renowned Early Learning School at New Town DLF BTM
EXTN.
Our play school airs to care for your child in a stimulating
safe, fun-filled environment. It symbolizes our conviction that
nurtured roots lay the foundation of a fully grown blossomed
tree.
Health, Wellbeing. Assurance, Right Next Door
State-of-the-art healthcare facilities at New Town DLF
BTM EXTN.
In these years of fast paced lives, your family's wellbeing is
5
foremost in our minds. Our healthcare centre will better the
latest in screening, diagnosis, and medical care with
competent medical professionals by your side, we will
make sure that you would always remain in the best of
health.
Comfort, Confidence, Peace of Mind Right Next Door.
Keeping your loves ones safe and secure at New Town, DLF
BTM EXTN.
Let New Town set your mind at rest when it comes to
security. Our advanced, state-of-the-art security system
ensures comfort & peace of mind for you and your loved
ones, with monitored gates, CCTV for parking and entrance
lobby, video surveillance system and a rigorously screened
24-hour security guard workforce, New Town offers you a
secure and a well-protected abode.” (emphasis supplied)
4 Responding to the representation held out by the developer, the
complainants booked flats in the residential project. The flat buyers entered into
agreements with the developer. Clause 11(a) of the ABA indicated that the
developer would endeavour to complete construction within a period of thirty-six
months from the date of the execution of the agreement save and except for
force majeure conditions. Clause 11(a) provided:
“11. (a) Schedule for Possession of the Said Apartment
The Company/LOC based on the present plans and
estimates and subject to all just exceptions, endeavors to
complete construction of the Said Building /Said Apartment
within a period of thirty six (36) months from the date of
execution of this Agreement unless there shall be delay or
failure due to Force Majeure conditions including but not
limited to reasons mentioned in Clauses 11(b) and 11(c) or
due to failure of Allottee to pay in time the Total Price and
other charges taxes, securities etc. and dues/payments or
any failure on the part of the Allottee to abide by all or any of
the terms and conditions of this Agreement.”
6
5 Force majeure stipulations were illustrated in sub-clauses (b) and (c) of
clause 11, which included delay due to the reasons beyond the control of the
developer and failure to deliver possession due to Government rules, orders or
notifications, respectively. Construction was behind schedule. The flat purchasers
were informed on 12 January 2011 that possession of the apartments was
expected to be completed by the middle of 2012. This assurance was not fulfilled.
By a communication dated 18 June 2013, the developers issued a revised
timeline intimating all flat buyers that the delivery of possession would commence
from October 2013. However, on 8 August 2013 another communication was
issued stating that the real estate industry was affected by an economic slowdown which had hampered the pace of construction. The date for handing over
possession was extended to June 2014. A tentative schedule for delivery was
indicated under which Towers D1 and D2 would be handed over by January
2014, and Towers A3 to A6, A7, B3 and B4 would be handed over by May 2014.
On 8 August 2014, the timelines for handing over possession were again
extended by the developers : under the revised schedule the flats in Towers D1
and D2 were to be handed over in August 2014, those in A1 to A-7 in February
2015, B1 to B6 in April 2015 and C1 to C4 in June 2015. On 4 May 2015, the
developers issued another communication indicating the progress of the work
and informed the purchasers that site visits had been initiated for the project “till
we receive the occupancy certificate for clusters A, B and C”. This is an
admission of the fact that until then the occupation certificate had not been
received. The obligation to handover possession within a period of thirty-six
months was not fulfilled.
7
6 The first batch of nine flat purchasers moved a consumer complaint before
the NCDRC complaining of a breach by the developer of the obligation,
contractually assumed, under the terms of the ABA. Since the nine complainants
purported to represent the entire group of flat purchasers, a notice of the
complaint under Section 12(1)(c) of the Consumer Protection Act 19863 was
published in the newspapers.
7 Numerous applications for impleadment were allowed by the NCDRC and
an amended complaint was ordered to be filed. On the complainants moving an
application under Section 12(1)(c), the NCDRC by its order dated 21 November
2017 permitted them to file the complaint on behalf or for the benefit of all the flat
buyers who were interested in the reliefs. However, flat buyers who had (i)
executed deeds of conveyance; or (ii) executed affidavits while accepting the
agreed compensation in full and final satisfaction; or (iii) received possession
within the stipulated time period; or (iv) had sold their flats after the execution of
the conveyance; or (v) who were subsequent purchasers having purchased the
flat after the execution of the conveyance deed were to remain outside the
purview of the proceedings. Further, the buyers from whom Preferential Location
Charges, charges for the preferential location of the apartment, were not charged
and were not chargeable were to remain out of the class on whose behalf or
benefit the complaint was instituted. On a challenge to the order, this Court by an
3
“CP Act 1986”
8
order dated 10 April 2018 directed:
“Since the complaint filed by the appellants was only by nine
persons jointly for their benefit, the same could not be treated
to be in representative capacity. Accordingly, the impugned
order is set aside.
Aggrieved parties are at liberty to file an appropriate fresh
application under Section 12(1)(c) of the Consumer
Protection Act, 1986 before the National Consumer Disputes
Redressal Commission within two weeks from today. The
same may be disposed of by the National Commission in
accordance with law within three months from the date of
filing of such an application.”
8 Pursuant to the liberty which was granted by this Court, an I.A.
4 was filed
before the NCDRC under Section 12(1)(c). The application was disposed of on
13 July 2018 which led to an appeal before this Court.
9 On 28 September 2018, this Court set aside the order of the NCDRC with
the following directions:
“Having heard learned counsel for the appellants, we are of
the view that the impugned judgment dated 13.07.2018
needs to be set aside. We set it aside and direct the National
Consumer Disputes Redressal Commission to treat the
complaint, as amended, that has been filed, as a complaint
filed on behalf of all 339 persons and to proceed on merits.
It will be open for the respondents to give their say on the
merits of each of the 339 complainants.
The Commission will decide the matter within a period of six
months from today.
The Civil Appeals are disposed of accordingly.”
4
IA No. 8083 of 2013
9
10 Procedural directions issued upon several impleadment applications
resulted in a further order of this Court of 8 May 2019 reiterating that the
complaint would be treated as having been filed on behalf of 339 persons. By its
order dated 28 September 2018, which was reiterated again on 8 May 2019, this
Court had laid down a peremptory time schedule of six months for the disposal of
the complaint. Eventually, on 2 July 2019, the complaint was dismissed by the
NCDRC.
11 Civil Appeal No 6239 of 2019 comprises of 83 appellants. Civil Appeal No
6303 of 2019 comprises of 88 appellants. Thus, there are before this Court a total
of 171 flat purchasers in the appeals. The complaint before the NCDRC, which
was confined by the order of this Court dated 28 September 2018 to 339
complainants, now covers a more restricted field of 171 flat purchasers.
Annexure-1 to Civil Appeal No 6239 of 2019 contains a tabulation of (i) names of
the flat purchasers; (ii) dates on which the flats were booked; (iii) dates on which
the ABAs were signed; (iv) dates by which possession was to be handed over
under the ABAs; and (v) dates on which the letter for possession was issued by
the developers.
12 The NCDRC divided the group of 339 flat buyers into six groups based on
whether or not they had taken possession, executed deeds of conveyance,
settled the dispute or sold the flats before or during the pendency of the
complaint or their applications for impleadment:
10
Group A: Complainants who took possession of their
flats before the filing of the complaint/impleadment
applications.
Group B: Complainants who took possession and
executed deeds of conveyance during the pendency
of the complaint/impleadment applications.
Group C: Complainants who took possession during
the pendency of the complaint/impleadment
applications but have not executed deeds of
conveyance.
Group D: Complainants who settled their dispute
during the pendency of the complaint/ impleadment
applications.
Group E: Complainants who sold their flats during the
pendency of the complaint/impleadment applications.
Group F: Complainants who have not taken
possession of the flats and have not executed a deed
of conveyance.
13 The NCDRC held that flat buyers in Groups A and B who had taken
possession before the filing of the complaint / impleadment applications and
those who took possession and executed deeds of conveyance before or during
the pendency of the proceedings would not be entitled to pursue their claims. The
execution of the deed of conveyance, according to the NCDRC, is a transfer of a
right in property and it is not within the jurisdiction of the Commission to entertain
a grievance that the conveyances have been entered into under coercion.
Additionally, according to NCDRC, under the conveyance deed, such flat buyers
had accorded their satisfaction to the services provided by the developer and
11
voluntarily discharged the developer of all its liabilities under the ABA. As regards
flat purchasers in Group C, the NCDRC noted that even those who have taken
possession but have not executed a deed of conveyance have voluntarily
discharged the developer. The NCDRC observed that flat buyers in Group C had
taken possession without protest, without its permission and without lodging any
complaint with it after taking the possession. Those in Group D who had settled
their dispute during the pendency of the complaint were held to be estopped from
pursuing their grievances. The NCDRC did not accept the contention of the flat
buyers in Group D that that they had settled the matter under coercion and undue
influence since, according to the NCDRC, no specific facts and circumstances
were pleaded by such flat buyers which made them surrender their free will. The
buyers in Group E who have sold their flats during the pendency of the complaint
were held to have no subsisting right. The NCDRC noted that as regards Group F
(complainants who had neither taken possession nor executed a conveyance), as
many as 337 out of 339 flat purchasers had in fact taken possession. The
NCDRC had to deal with the claims of two remaining complainants, who had
accepted the delayed compensation but did not accept possession. Their
complaints were dismissed.
14 The primary grounds on which compensation have been sought before the
NCDRC were:
(i) Delay in handing over possession of the flats;
(ii) Reimbursement of taxes and interest charged to the flat purchasers
under clause 1.10 of the ABA;
12
(iii) Deficiency in providing amenities;
(iv) Levy of electricity charges by the developer; and
(v) Failure to construct the club house.
15 The NCDRC, in the course of its judgment, observed that delay in the
handing over of flats to the flat purchasers was admitted. While recording a
finding of fact that there was an admitted delay on the part of the developer, the
NCDRC held that the agreements provided compensation at the rate of Rs 5 per
square foot of the super area for every month of delay. The NCDRC held that the
flat purchasers who agreed to this stipulation in the agreements were not entitled
to seek any amount in addition. Paragraph 470 of the judgment of the NCDRC
contains its finding:
“470. There is no dispute to the fact that the completion of the
project had been delayed. Delay had been acknowledged by
the opposite parties. They had also offered to these
complainants the delayed compensation calculated @ Rs 5/-
per sq. ft. of the super area.”
The NCDRC observed that the developer had while computing the final demand
made an adjustment on account of delayed compensation at the rate stipulated in
the ABA. The flat purchasers having been provided credit at the rate agreed by
the developers, it was held that no further entitlement existed under the law. In
the view of the NCDRC, the flat purchasers had failed to prove that the stipulation
contained in the agreement for the payment of compensation at Rs 5 per square
foot was unreasonable. In taking this view, the Commission has lent support to its
decision by relying upon the decisions of this Court in DLF Homes Panchkula
13
Pvt. Ltd. v. D S Dhanda, Etc.5
(“Dhanda”) and Ghaziabad Development
Authority v. Balbir Singh6
(“Balbir Singh”). On the merits of the other
grievances, the NCDRC has held that
(i) The charges recovered towards tax and interest are in terms of clause
1.10 of the ABA;
(ii) Charges recovered for electricity are in terms of the ABA;
(iii) The levy of parking charges is valid; and
(iv) The club house has been constructed.
16 In order to facilitate the final disposal of the Civil Appeals, counsel
appearing on behalf of the appellants formulated the nature of the grievances of
the flat buyers in the written submissions tendered during the hearing. Mr
Prashant Bhushan, learned Counsel appearing for the appellants has formulated
his submissions under the following heads:
(i) There is a gross delay ranging between two and four years in handing
over possession and the flat buyers ought not to be constrained by the
terms of the agreement which are one-sided and unreasonable;
(ii) The execution of conveyances or settlement deeds would not operate
to preclude the flat buyers from claiming compensation. The emails of
the developer clearly indicate that the flat buyers were not permitted to
execute conveyances or to receive possession under protest;
(iii) The amenities which have been contracted for have not been provided
5
2019 SCC OnLine SC 689
6
(2004) 5 SCC 65
14
by the developers; and
(iv) The flat buyers are not liable to indemnify the developer for the demand
of interest and penalty raised by the tax authorities as a result of the
failure to deposit the tax on time. During the oral arguments, it was
clarified that only interest has been recovered from the flat buyers.
The above submissions of Mr Prashant Bhushan have been reiterated in the
submissions urged before the Court by Mr Bishwajit Bhattacharya, learned Senior
Counsel appearing on behalf of another group of purchasers. Mr R
Balasubramanian, learned Senior Counsel has, while adopting the submissions
which were urged by Mr Prashant Bhushan, advanced submissions on the levy of
electricity charges and charges for parking spaces.
17 Opposing the submissions which have been urged on behalf of the
appellants, Mr Pinaki Misra, learned Senior Counsel urged that:
(i) Despite the order of this Court dated 28 September 2018, no evidence
has been led by the complainants to discharge the onus placed upon
them to establish coercion or duress while executing conveyances or
settlements;
(ii) Possession of the complex, which is situated on land admeasuring
about 27 acres and comprising of 813 apartments in nineteen towers
has been handed over between four to six years ago and the developer
has transferred his right, title and interest to the Residents‟ Welfare
Association (“RWA”);
15
(iii) The allottees have benefited by the appreciation in the value of their
flats;
(iv) Out of 171 applicants, 145 have received compensation at the agreed
rate while handing over possession. The allotments were escalation
free and the burden of increased costs has been borne by the
developer;
(v) Under clause 14 of the ABA, the flat buyers have been compensated at
the rate of Rs 5 per square foot per month which would work out to
about Rs 7500 per month for a flat admeasuring 1500 square feet. No
proof or measure of actual loss suffered has been adduced;
(vi) The facts pertaining to the appellants would indicate that:
(a) Eighteen appellants executed conveyances before filing the
complaints;
(b) Fifty-four appellants executed conveyances during the course
of the proceedings;
(c) Fifty appellants executed conveyances after the impugned
judgment;
(d) The above individuals include 11 who have entered into
written settlement deeds;
(e) There is no delay in offering possession to seven appellants;
and
(f) Three appellants are continuing to agitate their grievances
despite having transferred their rights in the flats. Out of 171
16
appellants, 122 executed conveyances before the complaint;
during the pendency of the proceedings or thereafter. Eleven
appellants who have entered into settlements did not raise a
ground of coercion prior to a reply which was filed in
December 2018 shortly before the final hearing;
(vii) As regards the construction of facilities and amenities, a club house
containing a swimming pool, gymnasium, tennis court, indoor
badminton court and squash courts has been constructed and an
occupation certificate has been received on 13 May 2019. The RWA is
conscious of the fact that difficulties in the allotment arose as a result of
the action of the Bangalore Development Authority7 which led to the
filing of writ proceedings before the High Court of Karnataka both by the
developer and the RWA. Even after the receipt of the occupation
certificate, the developers have been corresponding with BDA for
permission to hand over possession to the RWA. Other amenities
including a school and health care facilities were going to be developed
in the entire township comprising of 80 acres of which the complex of
27 acres was a part. The flat buyers were aware of the fact that under
the terms of the ABA, the allottees have no right, title or interest in the
amenities outside their residential complex and forming a part of the
wider complex of 80 acres. Moreover, this issue is rendered academic
since the area around DLF township has become urbanized where
adequate facilities are available;
7
“BDA”
17
(viii) Clauses 1.3, 1.10, 2 and 3 require the allottees to bear tax liabilities
including towards works contract tax. When the project commenced in
2009, there was an absence of clarity in regard to the liability on
account of works contract tax which was settled eventually by the
judgment of this Court in Larsen and Toubro Limited v. State of
Karnataka8
. It was as a result of this judgment that the issue was
settled following which, the developer while computing the amount
payable in the final statements of accounts passed on the liability on
account of the interest (but not towards penalty) on a proportionate
basis in terms of clause 1.10 of the ABA;
(ix) Clause 23(b) entitles the developer to raise a demand on a
proportionate basis from the flat buyers for electricity charges. Initially,
BESCOM provided a connection for electricity but subsequently as a
substantial load was required, the developer was permitted to build its
own electricity sub-station. This was built at a cost of Rs. 18.01 crores
for which the pro rata cost could be allocated to flat buyers in terms of
clause 23(b); and
(x) The price of the apartment, as agreed in the ABA, included in the
breakup, parking charges for exclusive use of earmarked parking
spaces. Parking charges were also revealed upfront in the brochure.
The appellants had erroneously relied on the decision of this Court in
Nahalchand Laloochand Private Limited v. Panchali Cooperative
8
(2014) 1 SCC 708
18
Housing Society Limited9
, which turned on the construction of the
provisions of the Maharashtra Apartment Ownership Act 1971 and
Development Control Regulations for Greater Bombay 1991. This has
subsequently been explained in the decision in DLF Limited v.
Manmohan Lowe10
. There is no prohibition in the Karnataka Apartment
Ownership Act upon the developer providing earmarked parking
charges in the breakup of the total price of the apartment.
The rival submissions will now be analysed.
Compensation for delayed possession
18 The fulcrum of the case of the developer rests on clause 14 of the ABA
which is in the following terms:
“14. The Allottee agrees and understands that if the company
is unable to give possession within the period as mentioned
above or such extended period as permitted under this
Agreement, due to reasons other than those mentioned in this
Agreement, then the Company agrees to pay only to the
Allottee and not to anyone else, subject to the Allottee, not
being in default under any terms of this Agreement
compensation @ Rs. 5/- per sq. feet of the Super Area of the
said apartment per month for the period of such Delay. The
adjustment of such compensation shall be done only at the
time of execution of the Conveyance Deed of the Said
Apartment to the Allottee first named under this Agreement
and not, earlier.”
19 Clause 11(a) of the ABA indicates that subject to “all just exceptions” the
developer endeavoured to complete construction within a period of thirty-six
months from the date of the execution of the agreement unless hindered by force
9
(2010) 9 SCC 536
10 (2014) 12 SCC 231
19
majeure conditions. Undoubtedly, the expression „endeavour‟ indicates that the
developer did not bind itself to an inflexible timeline of thirty-six months. But then
again, the timeline of thirty-six moths was subject to just exceptions and could be
excused in the event of force majeure conditions coming into operation. By the
provisions of clause 14, the developer agreed to compensate the flat buyers at
the rate of Rs. 5 per square feet of the super area of the apartment per month for
the period of delay. According to the developer (i) the flat purchasers are bound
by the above stipulations under which their entitlement was to receive
compensation at the agreed rate (and hence not beyond); and (ii) no evidence
has been adduced to indicate that the rate which has been prescribed in the
agreement is unreasonable. The developer relies on the observation in the
decision of this Court in Dhanda11 that when parties have agreed to a
consequence of delay in handing over possession, there must be exceptional
and strong reasons for the consumer fora to award compensation at more than
the agreed rate. In assessing these submissions, we must at the outset note the
submission of Mr Prashant Bhushan, learned Counsel that:
“There are a total of 4 blocks in „WESTEND HEIGHTS‟
project. In Blocks A, B and C, the delay is huge, over 4 years.
For block D, the average delay is 2 years. Out of 339
complainants, for 268, the delay is huge, over 4 years.
The Builder sought repeated extension of time to deliver
possession, vide communications dated 18.06.201312
,
8.8.201313, 8.8.201414, 4.5.201515 etc.”
11 2019 SCC OnLine SC 689
12 Annexure A9 @ page 929
13 Annexure A10 @ page 932, 933
14 Annexure A11 @ page 936
15 Annexure A12 @ page 938
20
20 The extent of the delay as set out in the above submissions has not been
controverted in the submissions which were urged before this Court by the
developer. On the contrary, the finding of the NCDRC in paragraph 470 of its
judgment is that:
“…there is no dispute to the fact that the completion of the
project has been delayed. Delay has been acknowledged by
the opposite parties….”
21 The existence and extent of the delay constitute an admitted factual
position. In fact, in the written submissions which have been filed by the
developer, it has been admitted that out of 171 appellants, 145 were given
compensation in terms of the rate prescribed in clause 14 of the ABA. Once the
developer has accepted that there was a delay on his part which triggered of the
liability to pay compensation (albeit, according to the developer, in terms of
clause 14) there can be no manner of doubt that:
(i) the developer assumed an obligation in terms of the ABA to endeavour to
hand over possession in thirty-six months of the date of the execution of
the agreement;
(ii) there was a failure on the part of the developer to comply with the
contractual obligation;
(iii) the failure of the developer was neither relatable to a “just exception” or the
prevalence of force majeure conditions referable to clause 11; and
(iv) the payment of compensation to the flat buyers or at least 145 of the group
of 171 represents an admission by the developer of its breach, thereby
triggering a liability to pay compensation.
21
22 The only issue which then falls for determination is whether the flat buyers
in these circumstances are constrained by the stipulation contained in clause 14
of ABA providing compensation for delay at the rate of Rs 5 per square feet per
month. In assessing the legal position, it is necessary to record that the ABA is
clearly one-sided. Where a flat purchaser pays the instalments that are due in
terms of the agreement with a delay, clause 39(a) stipulates that the developer
would “at its sole option and discretion” waive a breach by the allottee of failing to
make payments in accordance with the schedule, subject to the condition that the
allottee would be charged interest at the rate of 15 per cent per month for the first
ninety days and thereafter at an additional penal interest of 3 per cent per annum.
In other words, a delay on the part of the flat buyer attracts interest at the rate of
18 per cent per annum beyond ninety days. On the other hand, where a
developer delays in handing over possession the flat buyer is restricted to
receiving interest at Rs 5 per square foot per month under clause 14 (which in the
submission of Mr Prashant Bhushan works out to 1-1.5 per cent interest per
annum). Would the condition which has been prescribed in clause 14 continue to
bind the flat purchaser indefinitely irrespective of the length of the delay? The
agreement stipulates thirty-six months as the date for the handing over of
possession. Evidently, the terms of the agreement have been drafted by the
developer. They do not maintain a level platform as between the developer and
purchaser. The stringency of the terms which bind the purchaser are not mirrored
by the obligations for meeting times lines by the developer. The agreement does
not reflect an even bargain.
22
23 On behalf of the flat purchasers it has been urged by Mr. R
Balasubramanian (a submission which has not been controverted in rejoinder)
that 95 per cent of the purchase price was paid during the course of the first two
and a half to three years. The agreement did not stipulate that the developer
would pay any interest on the amount which had already been received. A large
chunk of the purchase price was thus available to the developer to complete
construction. The court must take a robust and common-sense based approach
by taking judicial notice of the fact that flat purchasers obtain loans and are
required to pay EMIs to financial institutions for servicing their debt. Delays on the
part of the developer in handing over possession postpone the date on which
purchasers will obtain a home. Besides servicing their loans, purchasers have to
finance the expenses of living elsewhere. To postulate that a clause in the
agreement confining the right of the purchaser to receive compensation at the
rate of Rs 5 per square foot per month (Rs 7,500 per month for a flat of 1500
square feet) precludes any other claim would be a manifestly unreasonable
construction of the rights and obligations of the parties. Where there is a delay of
the nature that has taken place in the present case ranging between periods of
two years and four years, the jurisdiction of the consumer forum to award
reasonable compensation cannot be foreclosed by a term of the agreement. The
expression deficiency of services is defined in Section 2 (1) (g) of the CP Act
1986 as:
“(g) "deficiency" means any fault, imperfection, shortcoming
or inadequacy in the quality, nature and manner of
performance which is required to be maintained by or under
any law for the time being in force or has been undertaken to
be performed by a person in pursuance of a contract or
23
otherwise in relation to any service”
24 A failure of the developer to comply with the contractual obligation to
provide the flat to a flat purchaser within a contractually stipulated period
amounts to a deficiency. There is a fault, shortcoming or inadequacy in the nature
and manner of performance which has been undertaken to be performed in
pursuance of the contract in relation to the service. The expression „service‟ in
Section 2 (1) (o) means a service of any description which is made available to
potential users including the provision of facilities in connection with (among other
things) housing construction. Under Section 14(1)(e), the jurisdiction of the
consumer forum extends to directing the opposite party inter alia to remove the
deficiency in the service in question. Intrinsic to the jurisdiction which has been
conferred to direct the removal of a deficiency in service is the provision of
compensation as a measure of restitution to a flat buyer for the delay which has
been occasioned by the developer beyond the period within which possession
was to be handed over to the purchaser. Flat purchasers suffer agony and
harassment, as a result of the default of the developer. Flat purchasers make
legitimate assessments in regard to the future course of their lives based on the
flat which has been purchased being available for use and occupation. These
legitimate expectations are belied when the developer as in the present case is
guilty of a delay of years in the fulfilment of a contractual obligation. To uphold
the contention of the developer that the flat buyer is constrained by the terms of
the agreed rate irrespective of the nature or extent of delay would result in a
miscarriage of justice. Undoubtedly, as this court held in Dhanda, courts
ordinarily would hold parties down to a contractual bargain. Equally the court
cannot be oblivious to the one-sided nature of ABAs which are drafted by and to
24
protect the interest of the developer. Parliament consciously designed remedies
in the CP Act 1986 to protect consumers. Where, as in the present case, there
has been a gross delay in the handing over of possession beyond the
contractually stipulated debt, we are clearly of the view that the jurisdiction of the
consumer forum to award just and reasonable compensation as an incident of its
power to direct the removal of a deficiency in service is not constrained by the
terms of a rate which is prescribed in an unfair bargain.
25 Numerous judgments of this Court have elaborated on the nature and
extent of the jurisdiction of the consumer forum to award just and reasonable
compensation. Since the decision of this Court in Lucknow Development
Authority v. M K Gupta16
, it has been a settled principle of law that the
jurisdiction of the consumer forum extends to the award of compensation to
alleviate the harassment and agony to a consumer. In Balbir Singh17
, a two
judge Bench of this Court, while explaining the ambit of the jurisdiction of the
adjudicatory fora under the CP Act 1986 observed:
“6…The word compensation is of a very wide connotation. It
may constitute actual loss or expected loss and may extend
to compensation for physical, mental or even emotional
suffering, insult or injury or loss. The provisions of the
Consumer Protection Act enable a consumer to claim and
empower the Commission to redress any injustice done. “
26 The court observed that the award of compensation has to be based on a
finding of loss or injury and must correlate to it. The court observed that no “hard
and fast rule” could be prescribed:
16 (1994) 1 SCC 243
17 (2004) 5 SCC 65
25
“8…No hard-and-fast rule can be laid down, however, a few
examples would be where an allotment is made, price is
received/paid but possession is not given within the period set
out in the brochure. The Commission/Forum would then need
to determine the loss. Loss could be determined on basis of
loss of rent which could have been earned if possession was
given and the premises let out or if the consumer has had to
stay in rented premises then on basis of rent actually paid by
him. Along with recompensing the loss the
Commission/Forum may also compensate for
harassment/injury, both mental and physical. “
Where possession has been given, one of the circumstances which must be
factored in is that the purchaser has been compensated by the increase in the
value of the property.
27 In R V Prasannakumaar v. Mantri Castles Pvt Ltd18 under the terms of
the ABA, possession of the flats was to be handed over to the buyers on 31
January 2014. However, the developer received an occupation certificate only on
10 February 2016 and it was thereafter from May 2016 that the developer started
issuing letters offering possession. Based on this, the NCDRC awarded
compensation in the form of interest at the rate of 6 per cent per annum. The
developer had pleaded that since the agreement provided compensation at the
rate of Rs. 3 per square foot per month for delayed possession, the purchasers
were not entitled to anything in addition. Dealing with the submission, this Court
observed:
“9. We are in agreement with the view of the NCDRC that the
rate which has been stipulated by the developer, of
compensation at the rate of 3 per sq. ft. per month does not
provide just or reasonable recompense to a flat buyer who
18 2019 SCC OnLine SC 224
26
has invested money and has not been handed over
possession as on the stipulated date of 31 January 2014. To
take a simple illustration, a flat buyer with an agreement of a
flat admeasuring a 1000 sq. ft. would receive, under the
agreement, not more than Rs. 3000/- per month. This in a city
such as Bangalore does not provide just or adequate
compensation. The jurisdiction of the NCDRC to award just
compensation under the provisions of the Consumer
Protection Act, 1986 cannot in the circumstances be
constrained by the terms of the agreement. The agreement in
its view is one sided and does not provide sufficient
recompense to the flat purchasers.”
The Court observed that there was a delay of two years and hence the award of
interest at the rate of 6 per cent was reasonable and justified.
28 In Pioneer Urban Land and Infrastructure Limited v. Govindan
Raghavan19, there was a delay of almost two years in obtaining an occupancy
certificate after the date stipulated in the ABA. As a consequence, there was a
failure to provide possession of the flat to the purchaser within a reasonable
period. This Court dwelt on the terms of the ABA under which the builder was
entitled to charge interest at 18 per cent per annum for the delay in payment of
instalments by the purchaser. On the other hand, the failure to provide
possession on the part of the developer was subject to a grace period of twelve
months followed by a termination notice of ninety days and a further period of
ninety days to the developer to effect a refund. Adverting to these clauses, the
court noted:
“6.4. A perusal of the apartment buyer's agreement dated 8-5-
2012 reveals stark incongruities between the remedies
available to both the parties. For instance, Clause 6.4(ii) of
the agreement entitles the appellant builder to charge interest
19 (2019) 5 SCC 725
27
@18% p.a. on account of any delay in payment of instalments
from the respondent flat purchaser. Clause 6.4(iii) of the
agreement entitles the appellant builder to cancel the
allotment and terminate the agreement, if any instalment
remains in arrears for more than 30 days. On the other hand,
as per Clause 11.5 of the agreement, if the appellant builder
fails to deliver possession of the apartment within the
stipulated period, the respondent flat purchaser has to wait for
a period of 12 months after the end of the grace period,
before serving a termination notice of 90 days on the
appellant builder, and even thereafter, the appellant builder
gets 90 days to refund only the actual instalment paid by the
respondent flat purchaser, after adjusting the taxes paid,
interest and penalty on delayed payments. In case of any
delay thereafter, the appellant builder is liable to pay interest
@9% p.a. only.
6.5. Another instance is Clause 23.4 of the agreement which
entitles the appellant builder to serve a termination notice
upon the respondent flat purchaser for breach of any
contractual obligation. If the respondent flat purchaser fails to
rectify the default within 30 days of the termination notice,
then the agreement automatically stands cancelled, and the
appellant builder has the right to forfeit the entire amount of
earnest money towards liquidated damages. On the other
hand, as per Clause 11.5(v) of the agreement, if the
respondent flat purchaser fails to exercise his right of
termination within the time limit provided in Clause 11.5, then
he shall not be entitled to terminate the agreement thereafter,
and shall be bound by the provisions of the agreement.”
Justice Indu Malhotra speaking for the Court noted:
“6.8. A term of a contract will not be final and binding if it is
shown that the flat purchasers had no option but to sign on
the dotted line, on a contract framed by the builder. The
contractual terms of the agreement dated 8-5-2012 are ex
facie one-sided, unfair and unreasonable. The incorporation
of such one-sided clauses in an agreement constitutes an
unfair trade practice as per Section 2(1)(r) of the Consumer
Protection Act, 1986 since it adopts unfair methods or
practices for the purpose of selling the flats by the builder.”
The Court observed that in these circumstances, the flat purchasers could not be
compelled to obtain possession which was offered almost two years after the
28
grace period under the agreement had expired. Hence, the NCDRC was held to
have correctly awarded interest at the rate of 10 percent per annum.
29 The decision of this Court in Dhanda20
has been relied upon by learned
Senior Counsel appearing on behalf of the developer as elucidating the principle
that where a flat buyers‟ agreement stipulates a consequence for delayed
possession, exceptional and strong reasons must be established before the
forum constituted under the Act of 1986 awards compensation in addition to what
has been contractually agreed. In Dhanda’s case, the SCDRC issued a direction
for handing over physical possession of the residential unit to the complainant
and for execution of a sale deed. In addition, compensation was awarded by way
of interest at the rate of 12 per cent per annum with effect from twelve months
after the stipulated date under the agreement. In an appeal by the developer, the
NCDRC directed that the rate of interest for a house building loan for the
corresponding period in a scheduled nationalised bank would be appropriate and
if a floating rate of interest was prescribed, the higher rate of interest should be
taken for the computation. A sum of Rs. 1 lac per annum from the date for
handing over possession to the actual date of possession was regarded as
appropriate in the facts of the case. In that case under the terms of the buyer‟s
agreements, possession was to be delivered within twenty-four months of the
execution of the agreement i.e. 10 February 2013 – failing which the developer
was liable to pay compensation at the rate of Rs. 10 per square foot per month
for the delay. The developer contended that construction activities were delayed
as a result of an injunction granted by this Court over a period of eight months
20 2019 SCC OnLine SC 689
29
and consequently sought an extension of the period for handing over possession
by one year. Alternatively, the developer offered to refund the money deposited
with interest at 9 per cent per annum. Construction of 258 independent floors was
completed while about 1,500 units were nearing completion. In two sets of Civil
Appeals which came up before this Court earlier, agreed terms were arrived at
providing for the award of interest at 9 per cent per annum from the date of
deposit till refund. While considering the order of the NCDRC, this Court
observed:
“16. The District Forum under the Consumer Protection Act,
1986 is empowered inter-alia to order the opposite party to
pay such amount as may be awarded as compensation to the
consumer for any loss or injury suffered by the consumer due
to the negligence of the opposite party including to grant
punitive damages. But the forums under the Act cannot award
interest and/or compensation by applying rule of thumb. The
order to grant interest at the maximum of rate of interest
charged by nationalised bank for advancing home loan is
arbitrary and no nexus with the default committed. The
appellant has agreed to deliver constructed flats. For delay in
handing over possession, the consumer is entitled to the
consequences agreed at the time of executing buyer's
agreement. There cannot be multiple heads to grant of
damages and interest when the parties have agreed for
payment of damages at the rate of Rs. 10/- per sq. ft. per
month. Once the parties agreed for a particular consequence
of delay in handing over of possession then, there has to be
exceptional and strong reasons for the SCDRC/NCDRC to
award compensation at more than the agreed rate.”
30 The orders of the SCDRC and NCDRC were held to be without any
foundation being led by the complainant and based purely on a “rule of thumb”.
The court noted that the amount of interest represents compensation to the
beneficiaries who are deprived of the use of the investment which has been
made and will take into its ambit the consequence of a delay in not handing over
30
possession. The court held that both the SCDRC and NCDRC awarded
compensation under different heads on account of a singular default of not
handing over possession. This was held not to be sustainable. The court held
that:
“19. Thus, we find that the complainant is entitled to interest
from the Appellant for not handing over possession as
projected as is offered by it but it is not a case to award
special punitive damages as one of the causes for late
delivery of possession was beyond the control of the
Appellant. Therefore, in view of the settlement proposal
submitted by the Appellant in earlier two set of appeals in
respect of same project, and to settle any further controversy,
the Appellant is directed as follows:
i) To send a copy of the occupation certificate to the
Complainants along with offer of possession. The Appellant
shall also direct the Jones Lang LaSalle - the real estate
maintenance agency, engaged by the Appellant to undertake
such maintenance works as is necessary on account of
damage due to non-occupation of the flats after construction
etc.
ii) It shall be open to the Complainants to seek the assistance of
the maintenance agency to attend to the maintenance work
which may arise on account of non-occupation or on account
of natural vagaries.
iii) Such maintenance work shall be completed by the Appellant
within two months of the offer of possession but the payment
of interest at the rate of 9 per cent per annum will be for a
period of two months from the date of offer of possession in
all situations.
v) Since the Complainants have been forced to invoke
jurisdiction of the consumer forums, they shall be entitled to
consolidated amount of Rs. 50,000/- in each complaint on all
accounts such as mental agony and litigation expenses etc.
The complainant shall not be entitled to any other amount
over and above the amount mentioned above.
vi) In case, the original allottee has transferred the flat, the
transferee shall be entitled to interest at the rate of 9 per cent
per annum from the date of expiry of three years from the
agreement or from the date of transfer, whichever is later.”
31
31 The judgment in Dhanda’s case does not prescribe an absolute embargo
on the award of compensation beyond the rate stipulated in the flat buyers‟
agreement where handing over of the possession of a flat has been delayed.
Dhanda’s case was preceded by consent terms which were presented before
this Court in two earlier civil appeals under which interest at the rate of 9 per cent
had been granted. The decision lays down that the award of interest cannot be
arbitrary and without nexus to the default which has been committed. Hence, the
award of interest at the maximum rate of interest charged by a nationalised bank
for advancing home loans was construed to be arbitrary. It was in this context
that the court observed that the parties having agreed to a consequence for
delay, exceptional and strong reasons must exist for the consumer fora to depart
from the agreed rate. The decision, in other words, does not lay down that there
is an absence of jurisdiction in the adjudicatory fora constituted under the CP Act
1986 to award remedial compensation to a flat buyer for the delay of the
developer in handing over possession on the agreed date.
32 In the present case, there exist, clear and valid reasons for not holding
down the flat buying consumers merely to the entitlement to receive
compensation at the rate of 5 per square foot per month in terms of clause 14 of
the ABA:
(i) There has been a breach on the part of the developer in complying with
the contractual obligation to hand over possession of the flats within a
period of thirty-six months of the date of the agreement as stipulated in
clause 11(a);
32
(ii) The failure of the developer to hand over possession within the
contractually stipulated period amounts to a deficiency of service within
the meaning of Section 2 (1) (g), warranting the invocation of the
jurisdiction vested in the NCDRC to issue a direction for the removal of
the deficiency in service;
(iii) The triggering of an obligation to pay compensation on the existence of
delay in handing over possession is admitted by the developer for, even
according to it, it has adjusted compensation at the agreed rate of Rs 5
per square foot per month to 145 out of the 171 appellants;
(iv) The agreement is manifestly one-sided: the rights provided to the
developer for a default on the part of the home buyer are not placed on
an equal platform with the contractual right provided to the home buyer
in the case of a default by the developer;
(v) There has been a gross delay on the part of the developer in
completing construction ranging between two and four years. Despite
successive extensions of time to deliver possession sought by the
developer, possession was not delivered on time;
(vi) The nature and quantum of the delay on the part of the developer are of
such a nature that the measure of compensation which is provided in
clause 14 of the ABA would not provide sufficient recompense to the
purchasers; and
(vii) Judicial notice ought to be taken of the fact that a flat purchaser who is
left in the lurch as a result of the failure of the developer to provide
33
possession within the contractually stipulated date suffers
consequences in terms of agony and hardship, not the least of which is
financial in nature. Having paid a substantial amount of the purchase
price to the developer and being required to service the debt towards
loan installments the purchaser is unable to obtain timely possession of
the flat which is the subject matter of the ABA.
But, it has been submitted by the developer – a submission which found
acceptance by the NCDRC – that the execution of the Deed of Conveyance by a
flat purchaser precludes a consumer claim being raised for delayed possession.
During the course of the proceedings before the NCDRC, the flat purchasers
relied upon the communications which were issued by the developer to
demonstrate that the purchasers were not permitted by the developer to execute
a Deed of Conveyance or to take possession under protest. The material which
was produced before the NCDRC supports this submission, which was urged
before the Court by Mr Prashant Bhushan, learned Counsel. By a communication
dated 16 February 2016, the developer informed a flat buyer that in terms of the
ABA, the allottee is required to take possession of the apartment by making
payments and executing documentation after the developer has obtained a
certificate for occupation from the competent authority and has offered
possession of the apartment to the allottee. The developer stated:
“We may also like to bring to your notice, that if the
acceptance of offer of possession terms is being conveyed by
the allottee under protest the Company will not be in a
position to hand over the possession and execute the
Conveyance Deed and as such your request to take over the
34
possession and execute the documents under protest is
untenable.”
33 By an email dated 24 December 2016, another flat buyer was informed
that:
“It would be a pleasure to progress with possession once you
submit the affidavit. However we can't accept any documents
to this effect under protest or claim of coercion. This affidavit
has to be unconditionally submitted and possession taken.”
By another communication dated 21 December 2016, a flat purchaser was
informed that:
“It was explained to you in our FDN itself and our earlier
reply/clarifications, that any kind of protest 'is not tenable if
you wish to take possession and register the property as well.
Kindly execute the affidavit as advised and proceed for further
process on registering the property.”
By a communication dated 1 December 2016, the developer informed a flat
purchaser that
“Your letter that you took possession and executed the
documents under protest is untenable and unacceptable and
the company will not be in a position to execute the
conveyance deed under protest.”
Copies of these communications are marked as Annexures P-28, P-29, P-30 and
P-31 to Civil Appeal 6239 of 2019.
34 The developer has not disputed these communications. Though these are
four communications issued by the developer, the appellants submitted that they
35
are not isolated aberrations but fit into a pattern. The developer does not state
that it was willing to offer the flat purchasers possession of their flats and the right
to execute conveyance of the flats while reserving their claim for compensation
for delay. On the contrary, the tenor of the communications indicates that while
executing the Deeds of Conveyance, the flat buyers were informed that no form
of protest or reservation would be acceptable. The flat buyers were essentially
presented with an unfair choice of either retaining their right to pursue their claims
(in which event they would not get possession or title in the meantime) or to
forsake the claims in order to perfect their title to the flats for which they had paid
valuable consideration. In this backdrop, the simple question which we need to
address is whether a flat buyer who seeks to espouse a claim against the
developer for delayed possession can as a consequence of doing so be
compelled to defer the right to obtain a conveyance to perfect their title. It would,
in our view, be manifestly unreasonable to expect that in order to pursue a claim
for compensation for delayed handing over of possession, the purchaser must
indefinitely defer obtaining a conveyance of the premises purchased or, if they
seek to obtain a Deed of Conveyance to forsake the right to claim compensation.
This basically is a position which the NCDRC has espoused. We cannot
countenance that view.
35 The flat purchasers invested hard earned money. It is only reasonable to
presume that the next logical step is for the purchaser to perfect the title to the
premises which have been allotted under the terms of the ABA. But the
submission of the developer is that the purchaser forsakes the remedy before the
36
consumer forum by seeking a Deed of Conveyance. To accept such a
construction would lead to an absurd consequence of requiring the purchaser
either to abandon a just claim as a condition for obtaining the conveyance or to
indefinitely delay the execution of the Deed of Conveyance pending protracted
consumer litigation.
36 It has been urged by the learned counsel of the developer that a
consequence of the execution of the Deed of Conveyance in the present case is
that the same ceases to be a transaction in the nature of “supply of services”
covered under the CP Act 1986 and becomes a mere sale of immovable property
which is not amenable to the jurisdiction of Consumer Fora. In Narne
Construction (P) Ltd. v. Union of India21
, this Court distinguished between a
simple transfer of a piece of immovable property and housing construction or
building activity carried out by a private or statutory body falling in the category of
„service‟ within the meaning of Section 2 (1) (o) of the CP Act 1986. This Court
held that:
“8. Having regard to the nature of transaction between the
appellant Company and its customers involved much more
than a simple transfer of a piece of immovable property it is
clear the same constitutes “service” within the meaning of the
Act. It was not the case that the appellant Company was
selling the given property with all its advantages and/or
disadvantages on “as is where is” basis, as was the position
in UT Chandigarh Admn v. Amarjeet Singh. It is a case where
a clear-cut assurance was made to the purchasers as to the
nature and extent of development that would be carried out
by the appellant Company as a part of package under which
a sale of fully developed plots with assured facilities was
made in favour of the purchasers for valuable consideration.
To the extent the transfer of site with developments in the
manner and to the extent indicated earlier was a part of the
21 (2012) 5 SCC 359
37
transaction, the appellant Company has indeed undertaken to
provide a service. Any deficiency or defect in such service
would make it accountable before the competent Consumer
Forum at the instance of consumers like the respondents.”
The developer in the present case has undertaken to provide a service in the
nature of developing residential flats with certain amenities and remains
amenable to the jurisdiction of the Consumer Fora. Consequently, we are unable
to subscribe to the view of the NCDRC that flat purchasers who obtained
possession or executed Deeds of Conveyance have lost their right to make a
claim for compensation for the delayed handing over of the flats.
37 However, the cases of the eleven purchasers who entered into specific
settlement deeds with the developers have to be segregated. In the case of these
eleven persons, we are of the view that it would be appropriate if their cases are
excluded from the purview of the present order. These eleven flat purchasers
having entered into specific deeds of settlement, it would be only appropriate and
proper if they are held down to the terms of the bargain. We are not inclined to
accept the contention of the learned counsel of the appellants, Mr. Prashant
Bhushan, that the settlement deeds were executed under coercion or undue
influence since no specific material has been produced on record to demonstrate
the same.
38 Similarly, the three appellants who have transferred their title, right and
interest in the apartments would not be entitled to the benefit of the present order
since they have sold their interest in the apartments to third parties. The written
38
submissions which have been filed before this Court indicate that “the two buyers
stepped into the shoes of the first buyers” as a result of the assignment of rights
and liabilities by the first buyer in favour of the second buyer. In HUDA v. Raje
Ram22
, this Court while holding that a claim of compensation for delayed
possession by subsequent transferees is unsustainable, observed that:
“7. Respondents in the three appeals are not the original
allottees. They are re-allottees to whom re-allotment was
made by the appellant in the years 1994, 1997 and 1996
respectively. They were aware, when the plots were reallotted to them, that there was delay (either in forming the
layout itself or delay in delivering the allotted plot on account
of encroachment etc). In spite of it, they took re-allotment.
Their cases cannot be compared to cases of original allottees
who were made to wait for a decade or more for delivery and
thus put to mental agony and harassment. They were aware
that time for performance was not stipulated as the essence
of the contract and the original allottees had accepted the
delay.”
Even if the three appellants who had transferred their interest in the apartments
had continued to agitate on the issue of delay of possession, we are not inclined
to accept the submission that the subsequent transferees can step into the shoes
of the original buyer for the purpose of benefiting from this order. The subsequent
transferees in spite of being aware of the delay in delivery of possession the flats,
had purchased the interest in the apartments from the original buyers. Further, it
cannot be said that the subsequent transferees suffered any agony and
harassment comparable to that of the first buyers, as a result of the delay in the
delivery of possession in order to be entitled to compensation.
22 (2008) 17 SCC 407
39
Amenities
39 The brochure that was issued by the developers spoke of a “Distinctive
DLF Living” while advertising the project, which was described as “DLF Westend
Heights”, New Town. This was described as “the premier choice for Bangalore
living…a premium residential enclave featuring spacious apartments with a rich
selection of amenities.” Westend Heights at New Town was described as a
project which was being developed on a land area of 27.5 acres. The brochure
specifically referred to the amenities being provided. Among them were (i) “The
most exclusive club in Bangalore”; (ii) a swimming pool; (iii) gymnasium/ aerobics
centre; and (iv) a restaurant and Bar together with other sports facilities. Besides
this, the brochure contained a representation of the setting up of a convenience
shopping centre with an array of outlets, a renowned early - learning school and
state of the art health care facilities. Clause 1.10(a) of the ABA, which imposes
the liability to bear taxes on the allottees states that this liability will be
proportionate to the ratio of the super area of the apartment to the total super
area of all the apartments and other “shops, clubs etc” in the said complex.
The grievance in regard to the alleged failure of the developer to provide
amenities may be divided into two segments:
(i) The club house; and
(ii) Other amenities
Club house
40 The developer has stated before the court that a club house containing
appurtenant facilities including a swimming pool, gymnasium, billiards room,
40
tennis court, indoor badminton court, squash court and community hall has been
fully constructed and an occupation certificate has been received on 13 May
2019. The developer has stated that under the building regulations, it has to
handover 5 per cent of the area of the group housing complex to BDA as a civic
amenities (“CA”) area. The RWA has to apply to BDA for allotment of the CA
area in its favour. Upon allotment, the RWA hands over the area to the builder for
construction of the club. The developer relinquished the CA area in favour of the
BDA, constituted an RWA and applied to BDA on 22 June 2010 for the allotment
of the CA site in favour of the RWA. The written submissions indicate that a
dispute over the charges demanded by BDA towards lease rent led to a writ
petition before the Karnataka High Court being instituted both by the developer
and the RWA which was allowed on 29 June 2015. The developer submitted a
building plan to the municipal body. A second writ petition had to be filed in which
the High Court on 18 October 2016 directed the municipal body to proceed with
the approval of the building plans. Sanction for the building plan was received on
18 May 2017 and after construction of the club building, an occupation certificate
was received on 13 May 2019. The developer has stated that it has been
following up with BDA to permit them to hand over possession and management
of the club to the RWA. Since permission of BDA has still not been received legal
action is contemplated again. The developer has produced photographs depicting
the amenities which have been provided within the precincts of the club house.
Membership fees for the club are stated to have been received in the account of
the RWA and not in the account of the developer. The position which has been
stated before the court as elucidated above has not been disputed by counsel for
41
the appellants. Hence, we find that there has been no breach by the developer of
the obligation to provide a constructed facility of a club for the RWA.
Other amenities
41 As regards the other amenities, the defence of the developer is that these
were to be developed as an integral element of the entire township of 80 acres of
which the project admeasuring 27 acres (comprised in Westend Heights) was a
part. The ABA stipulates that allottees of the complex have no right, title and
interest in respect of the amenities or facilities outside the residential complex,
which lie within the larger township. According to the developer, no part of the
consideration which was paid by allottees, including the appellants, was towards
the amenities and facilities falling outside the boundary of the complex. In this
regard, the developer relies on the following stipulation accepted by allottees
under clause 5 of the Booking Application Form:
“The applicant confirms and represents that he has not
made any payment to the Company in any manner
whatsoever and that the Company has not indicated /
premised / represented / given any impression of any kind in
an explicit or implicit manner whatsoever, that the Applicant
shall have any right, title or interest of any in whatsoever in
any lands, buildings, common areas, facilities and amenities
failing outside the Said Complex…”
The above stipulation is reiterated under clause 1.21 of the ABA:
“The allottee acknowledges and confirms that the allottee is
not entitled to or has not paid for the lands outside the said
land/said complex whether the same is within said project or
other. The said project would comprise of many complexes
similar on different to said complex. Allottee has not paid any
amount towards any other lands, areas, facilities and
amenities including but not limited to those listed below, and
42
as such, the allottee shall have no right interest of any nature
whatsoever in the same and the same are specifically
excluded from the scope of this agreement. The allottee
acknowledges that the ownership of such land and facilities
and amenities shall vest solely with the company/LDC and its
associate companies subsidiaries and they alone shall have
sole right and absolute authority to deal with the same
including their usage and manner/method of use, disposal
etc. creation of rights in favour of other person by way of sale,
transfer, lease Joint venture, collaboration or any other
including transfer of government, semi-government, any other
person. "
42 Now, it is correct as the developer contends that the flat purchasers have
no right, title or interest in respect of the amenities which were to be constructed
by the developer as a part of the larger township of New Town. The entire area
comprised 80 acres of which Westend Heights was situated on 27 acres. The
absence of a title or interest in the flat purchasers in the amenities to be provided
outside the area of 27 acres begs the question as to whether there was a breach
of a clear representation which was held out to the flat purchasers by the
developer. A deficiency under Section 2(1)(g) means a fault, imperfection,
shortcoming or inadequacy in the quality, nature and manner of performance.
This may be required to be maintained under law or may be undertaken to be
performed in pursuance of a contract or otherwise in relation to any service. The
builder invited prospective flat purchasers to invest in the project of Westend
Heights on the basis of a clear representation that the surrounding area of New
Town situated on 80 acres was being developed to provide a wide range of
amenities including a shopping centre, health care facilities and an early learning
school. The developer has failed to provide these amenities. In the reply, the
developer has stated that:
43
“It is stated that School, Commercial Complex and Health
clinic are part of the facility which will be provided upon the
completion of the Whole New Town project as these facilities,
with existing population cannot sustain these facilities. Every
matter has to be adjudicated in light of its own facts and
circumstance…”
In the written submissions of the developer, the failure to provide the amenities is
sought to be glossed over by contending that:
“…the issue of these facilities has since become completely
academic since the area around the DLF Township has
already become totally urbanized and well developed thanks
in larger measure due to the DLF‟s activities in the area and
there are now many proximate hospitals, schools, shopping
areas that have mushroomed in the immediate vicinity and
neighbourhood of the DLF Township which are in fact being
regularly and conveniently used by the residents of the DLF
residential complex which include the Appellants herein. As
such, there is no loss or claim for any damages that could be
said to have accrued to the Appellants either under the ABA
or otherwise under this alleged head of claim.”
43 In other words, what the developer holds out as a defence is that though
there has been a failure on their part to provide the amenities, the flat buyers
have the benefit of facilities in the surrounding area which has become
urbanised. We cannot agree with this line of submissions. The reply of the
developer seeks to explain the failure to construct the facilities on the ground that
the “existing population cannot sustain these facilities” – a school, commercial
complex and health care facilities. This is a case involving an experienced
developer who knew the nature of the representation which was being held out to
the flat purchasers. Developers sell dreams to home buyers. Implicit in their
representations is that the facilities which will be developed by the developer will
provide convenience of living and a certain lifestyle based on the existence of
44
those amenities. Having sold the flats, the developer may find it economically
unviable to provide the amenities. The flat purchasers cannot be left in the lurch
or, as in the present case, be told that the absence of facilities which were to be
provided by the developer is compensated by other amenities which are available
in the area. The developer must be held accountable to its representation. A flat
purchaser who invests in a flat does so on an assessment of its potential. The
amenities which the builder has committed to provide impinge on the quality of
life for the families of purchasers and the potential for appreciation in the value of
the flat. The representation held out by the developer cannot be dismissed as
chaff. True, in a situation such as the present it may be difficult for the court to
quantify the exact nature of the compensation that should be provided to the flat
buyers. The general appreciation in land values results in an increase in the
value of the investment made by the buyers. Difficulties in determining the
measure of compensation cannot however dilute the liability to pay. A developer
who has breached a clear representation which has been made to the buyers of
the amenities which will be provided to them should be held accountable to the
process of law. To allow the developer to escape their obligation would put a
premium on false assurances and representations made to the flat purchasers.
Hence, in factoring in the compensation which should be provided to the flat
buyers who are concerned in the present batch of appeals, we would necessarily
have to bear this issue in mind.
Tax
44 The ABA contained specific provisions in regard to the payment of taxes.
45
Clause 1.3 of the ABA provided:
“1.3 The Allottee shall make the payment of the Total price as
per the payment plan set out in annexure -III of this
Agreement. Other charges, securities, payments etc. (as
specified in this Agreement), Taxes and increase thereof (as
provided in clause 1.10) shall be payable by the Allottee, as
and when demanded by the Company.”
Clause 1.10 contained a specific provision in regard to the obligation of the
allottee to pay taxes in addition to the total price. Clause 1.10 provided:
“1.10. The Allottee agrees and understands that in addition to
Total price, the Allottee shall be liable to pay the Taxes, which
shall be charged and paid as under:
a) A sum equivalent to the proportionate share of Taxes shall
be paid by the Allottee to the Company. The Proportionate
share shall be the ratio of the Super Area of the said
Apartment to the total super area of all the apartments other
buildings shop, club etc. in the said complex.
b) The Company shall periodically intimate to the Allottee
herein, on the basis of certificates from a Chartered Engineer
and /or a Chartered· Accountant, the amount payable as
stated above which shall be final and binding on the Allottee
and the Allottee shall make payment of such amount within
30 (thirty days) of such intimation.”
The ABA also contains the following provisions:
“2. Payment for taxes on land, wealth-tax, cesses etc. by
Allottee: -
The Allottee agrees and confirms to pay all Government
rates, tax on land, municipal tax, property taxes, wealth
tax, Building and Other Construction Workers Welfare
Fund (Cess),taxes, one time building tax, luxury tax if any,
fees or levies of all and any kind by whatever name
called, whether levied or Leviable now or in future by the
Government or municipal authority or any other
governmental authority on the Said Complex and I or the
Said Building or land appurtenant thereto as the case
46
may be as assessable or applicable from the date of the
Application if the Said Apartment is assessed separately
and if the Said Apartment is not assessed separately then
the Allottee shall pay directly to the concerned authority
and if the same is levied on or paid by the Company or
the Allottee then the same shall be borne and paid by the
Allottee on pro-rata basis and such determination of
proportionate share by the Company and demand shall
be final and binding on the Allottee. However, if the Said
Apartment is assessed separately the Allottee shall pay
directly to the Government Authority.
3. Amount paid by Allottee with Application
The Allottee has paid a sum of Rs. 3,00,000/- (Rupees 3
Lakhs only) alongwith the Application, the receipt of
which the Company doth hereby acknowledge and the
Allottee agrees to pay the remaining price of the Said
Apartment as prescribed in schedule of payments
(Annexure-III) attached with this Agreement along with all
other charges, Taxes, securities etc. as mentioned in this
Agreement and as per the de-mand raised by the
Company in accordance with the Agreement.”
The ABA contains the definition of taxes in the following terms:
“"Taxes" shall mean any and all taxes payable by the
Company/LOC and/or its contractors, suppliers, consultants,
etc. by way of value added tax (VAT), state sales tax, central
sales tax, works contract tax, service tax, cess, levies and
educational cess and any other taxes levies, charges by
whatever name called levied and collected by Government
Agency in connection with Development / construction of the
Said Apartment/Said Building/Said Complex.”
The expression total price is also defined in the ABA so as to be exclusive inter
alia of taxes.
45 The two certificates of the Chartered Accountant issued on 26 July 2013
and 9 August 2014 indicate that taxes inclusive of interest have been recovered.
According to the appellants, the builder admitted that it had “not properly
47
discharged” his liability towards taxes for a period of thirty-six months between
2011-2012 and 2013-2014 and that tax dues were paid on 25 March 2015
together with penalty and interest. Hence, it has been urged that the liability to
pay interest which arose on account of the default of the developer in discharging
the tax liability on time cannot be fastened upon the buyers.
46 On behalf of the developer it has been submitted that when construction
commenced in 2009, there was an absence of clarity on whether works contract
tax was liable to be paid in relation to agreements between owners-developers
and allottees of apartments where the apartments were to be delivered in future.
In 2013, this Court delivered its judgment in Larsen and Toubro Limited v State
of Karnataka23 as a result of which the liability towards works contract tax was
adjudicated upon. Consequently, while computing the amount payable in the final
statements of accounts, the developer passed on the interest burden but not the
penalty on a proportionate basis in terms of clause 1.10. The allottees were
required to pay their proportionate share of the works contract tax in terms of the
ABA and the final demand was raised at the time of the offer of possession.
47 The specific conditions contained in the ABA clearly imposed the liability to
bear the proportionate share of taxes on the purchasers. Clauses 1.3 and 1.10
leave no manner of doubt in regard to the position. The developer has offered an
explanation of why as a result of pending litigation, the dues towards works
contract tax were not paid earlier. Indeed, if they were paid earlier, the
purchasers would have been required to reimburse their proportionate share of
23 (2014) 1 SCC 708
48
taxes earlier as well. No part of the penalty imposed on the developer has been
passed on to the purchasers. In view of the terms of the ABA and the explanation
which has been submitted by the developer, there is no deficiency of service in
regard to the demand of interest payable on the tax which was required to be
deposited with the revenue.
Electricity
48 The submission by Mr. R. Balasubramanian, learned Senior Counsel is
that the initial collection of Rs. 1.50 lacs from each buyer towards BESCOM
/BWSSB charges for electricity and water are admitted. Subsequently, invoking
clause 23(b) of the ABA, the developer collected two lacs from each buyer
towards additional electricity charges. The appellants contest the entitlement of
the developer to claim these charges.
Clause 23(b) of the ABA is in the following terms:
“23. (b) Payments and other charges for bulk supply of
electrical energy
If Company or the Maintenance Agency decides to apply for
and thereafter receives permission from BESCOM or from
any other body / commission/ regulator/ licensing authority
constituted by the Government of Karnataka for such
purpose, to receive and distribute bulk supply of electrical
energy in the Said Project/Said Complex then the Allottee
undertakes to pay on demand to the Company proportionate
share as may be determined by the Company of all payments
and charges paid/ payable by the Company or the
Maintenance Agency to BESCOM…The proportionate share
of cost incurred by the Company for creating infrastructure
like HT feeder, EHT sub stations etc shall also be payable by
the Allottee on demand.”
49 According to the developer, initially an electricity connection was provided
49
by BESCOM without insisting on the requirement of an electric sub-station.
Subsequently as occupation certificates were received for additional towers,
BESCOM required a dedicated electric sub-station which was constructed by the
developer at a cost of Rs. 18.01 crores. The pro rata cost for setting up this
additional infrastructure was, according to the developer, payable by the
allottees. When offers for possession were issued to the buyers, the following
stipulation was contained in the letter:
“Our initial effort was to obtain and energize the power supply
to the entire project of 1830 apartments through individual ll
KV feeders from Golahalli 66/llKV Substation. On this basis,
the costing for infrastructure towards provisioning of utilities
as per clause 1.14, 1.15, 23(b) and JDC of ABA was
estimated at rate Rs. 127.96/sft., which was reflected in the
Final Demand to D Block customers. However, after a
detailed evaluation of the load requirement for the project as
per norms, BESCOM has now stipulated that, in accordance
with clause 3.2.4 of KERC Regulations, we establish a
dedicated 66/11 kv Substation within our project site to cater
to the needs of the project, instead of the earlier proposed
scheme of 11 Kv feeders from Golahalli. The increase in cost
because of this new sub-station and allied works, over and
above the originally envisaged 11KV scheme is estimated
@Rs. 18.01 Cr., thereby increasing the total infrastructure
cost recovery towards provisioning of utilities to Rs.
188.00/sft. In view of the above said amounts are being
recovered on the basis of provisional estimates. On
commissioning and energizing the substation, the company
shall arrange a certificate from independent chartered
accountant/ chartered engineer to arrive at the actual cost
incurred. Your share of the said actual cost by the Company
shall be duly intimated to you accordingly. If it is found that
excess amount paid by you, over and above the actual cost
incurred by the company, said excess amount so collected
shall be refunded to you without interest. If the actual
expenses exceeds the estimated amount computed @Rs.
188/-sq. ft. then demand for the shortfall amount shall be
raised through further demand on the owner of the property
and shall be payable by you. We would further like to bring to
your kind attention that the provision of 66/llKV substation will
ensure better quality uninterrupted power supply as
compared with the previously planned scheme of
11KV‟reeders.”
50
50 Mr. R. Balasubramanian, learned Senior Counsel contends that clause
23(b) relates to receiving and distributing the bulk supply of electrical energy to
“the said project /said complex” which is defined as “project under the name and
style of “New Town DLF BTM Extension”. According to the submission, the
charges have been collected for the entire New Town project and not for
Westend Heights alone. In this context it has also been submitted that distribution
of electricity is governed by the KERC Regulations 2006. While planning the
project, the developer calculated the cost of the 66/11 KV sub-station and
collected charges from each of the 1830 buyers. Hence, it has been submitted
that there was no requirement of additional bulk supply of electricity for the
nineteen hundred buyers. In this context, the formulation in the written
submissions is extracted below:
“(under) regulation 3.02 (e) of KERC (Conditions of Supply of
Electricity by the Distribution Licensee) Regulations 2004, it is
mandatory to set up 66 KV supply line/ KV substation if the
demands goes beyond 7500 KVA. Further under regulation
3.2.4 KERC (Recovery of Expenditure for Supply of
Electricity) Regulations 2004 : “In case of layouts/buildings
requiring power supply and the requisitioned load is more
than 7500 KVA, the developer/ Applicant shall provide the
space for erection of sub-station and also bear the entire
charges of such a sub-station and associated
lines/equipments. The work shall be carried out either by the
Licensee duly recovering the charges as per estimate or by
the Applicant himself through appropriate class of licensed
contractor by paying 10% of the estimate as supervision
charges to the Licensee.”
51 The NCDRC has upheld the collection of the charges towards electricity
51
based on the terms of the ABA. There is no infirmity in the finding of the NCDRC,
which is based on the provisions contained in clause 23(b) of the ABA. The
charges recovered are not contrary to what was specified in the contract between
the parties.
Parking
52 The appellants seek a refund of an amount of Rs. 2.25 lacs collected from
each buyer towards car parking. The submission is that under Section 3(f) of the
Karnataka Apartment Ownership Act 197224
, common areas and facilities
include parking areas. According to the appellants, the flat buyers had already
paid for the super area in terms of clause 1.6 of ABA including common areas
and facilities which would be deemed to include car parking under the KAO Act.
The relevant portion of clause 1.6 is extracted below:
“1.6. The Allottee agrees that the Total price of the said
Apartment is calculated on the basis of its Super Area only
(as indicated in clause 1.1.) except the parking space,
additional car parking space which are based on fixed
valuation…."(emphasis supplied)
53 We are unable to accede to the above submission. The ABA contained a
break-up of the total price of the apartment. Parking charges for exclusive use of
earmarked parking spaces were separately included in the break-up. The parking
charges were revealed to the flat buyers in the brochure. The charges recovered
are in terms of the agreement.
54 The decision of this Court in Nahalchand Laloochand Private Limited v.
24 “KAO Act”
52
Panchali Cooperative Housing Society Limited25 turned on the provisions of
the Maharashtra Ownership Flats Act 1971, as explained in the subsequent
decision of this Court in DLF Limited v. Manmohan Lowe26
. The demand of
parking charges is in terms of the ABA and hence it is not possible to accede to
the submission that there was a deficiency of service under this head.
55 For the above reasons we have come to the conclusion that the dismissal
of the complaint by the NCDRC was erroneous. The flat buyers are entitled to
compensation for delayed handing over of possession and for the failure of the
developer to fulfil the representations made to flat buyers in regard to the
provision of amenities. The reasoning of the NCDRC on these facets suffers from
a clear perversity and patent errors of law which have been noticed in the earlier
part of this judgment. Allowing the appeals in part, we set aside the impugned
judgment and order of the NCDRC dated 2 July 2019 dismissing the consumer
complaint. While doing so, we issue the following directions:
(i) Save and except for eleven appellants who entered into specific
settlements with the developer and three appellants who have sold their
right, title and interest under the ABA, the first and second respondents
shall, as a measure of compensation, pay an amount calculated at the
rate of 6 per cent simple interest per annum to each of the appellants.
The amount shall be computed on the total amounts paid towards the
purchase of the respective flats with effect from the date of expiry of
thirty-six months from the execution of the respective ABAs until the
25 (2010) 9 SCC 536
26 (2014) 12 SCC 231
53
date of the offer of possession after the receipt of the occupation
certificate;
(ii) The above amount shall be in addition to the amounts which have been
paid over or credited by the developer at the rate of Rs 5 per square
foot per month at the time of the drawing of final accounts; and
(iii) The amounts due and payable in terms of directions (i) and (ii) above
shall be paid over within a period of one month from the date of this
judgment failing which they shall carry interest at the rate of 9 per cent
per annum until payment.
56 The civil appeals are accordingly allowed in the above terms.
57 Pending application(s), if any, shall stand disposed of.
…….………….…………………...........................J.
[Dr. Dhananjaya Y Chandrachud]
…….…………………………...............................J.
[K M Joseph]
New Delhi;
August 24, 2020.
REPORTABLE
IN THE SUPREME COURT OF INDIA
CIVIL APPELLATE JURISDICTION
Civil Appeal No. 6239 of 2019
Wg. Cdr. Arifur Rahman Khan ...Appellants
and Aleya Sultana and Ors.
Versus
DLF Southern Homes Pvt Ltd ...Respondents
(now Known as BEGUR OMR Homes Pvt. Ltd.) and Ors.
With
Civil Appeal No. 6303 of 2019
2
J U D G M E N T
Dr. Dhananjaya Y. Chandrachud, J
1 The National Consumer Disputes Redressal Commission1
dismissed a
consumer complaint filed by 339 flat buyers, accepting the defence of DLF
Southern Homes Pvt. Ltd. and Annabel Builders and Developers Pvt. Ltd. that
there was no deficiency of service on their part in complying with their contractual
obligations and, that despite a delay in handing over the possession of the
residential flats, the purchasers were not entitled to compensation in excess of
what was stipulated in the Apartment Buyers Agreement2
.
2 The complaint before the NCDRC was initially instituted by nine flat
buyers. These nine complainants had booked residential flats in a project called
Westend Heights at New Town, DLF, BTM Extension at Begu, Bengaluru. The
project was being developed in an area admeasuring 27.5 acres and was to
consist of 1980 units, spread across nineteen towers each consisting of a stilt
and eighteen floors.
3 The Brochure of the first respondent advertised the nature of the project
and the amenities which would be provided to buyers. It held out the following
representations on the basis of which buyers were induced to invest:
1
“NCDRC”
2
“ABA”
3
“New Town - the premier choice for Bangalore living. A
premium residential enclave that celebrates life in all its
resident splendor. Featuring spacious apartments and a rich
selection of amenities, you will find in New Town, a
residence specially appointed to maximize your comfort
and convenience. In New Town premium high rise
apartments are set against the backdrop of a vibrant living
environment where fun, comfort, security, and serenity blend
in perfect unison. Life at New Town satisfies all your needs
and fulfils your heart's desire. Imagine a place where
leisurely pursuits are always within reach. Imagine living
where convenience is never more than around the
corner.
Westend Heights at New Tower DLF, BTM Extn.
Designs, keeping in mind the modern day requirements
and meeting them with apt amenities, Westend Heights is
the first phase of New Town, with premium high-rise
apartments at affordable prices. The complex brings you
comfort living embodied in individual towers overlooking
sprawling parks and vistas. This project is being developed in
a land area of 27. 5 acres. The project consists of 1980 units
spread across 19 towers that are Stilt+ 18 floors high.
Amenities
Fun, Fitness, Leisure, Right Next Door
The most exclusive Club in Bangalore at New town, DLF
BTM, EXTN,
The Club set amidst a very comfortable setting is an
impressive feature of New Town. It is specially designed to
take care of all stresses brought on by the modern world.
Altogether a beautiful composition, that blends seamlessly
with your lifestyle.
Swimming Pool:
Gymnasium/ Aerobics Centre
Restaurant & Bar
4
Billiards Room
Banquet Hall
Tennis Courts
Cards Room
Squash Courts
Spa, Massage & Beauty Parlour
Ease, Enjoyment, Convenience. Right Next Door
Convenient shopping facilities at New Town, DLF BTM
EXTN
Shop with ease at our convenience shopping centre, well
equipped to handle your everyday needs. The shopping
centre will offer an array of outlets to make your life a
trouble free affair.
Experience convenience at your doorstep
Hope, Dreams, Future. Right Next Door
Renowned Early Learning School at New Town DLF BTM
EXTN.
Our play school airs to care for your child in a stimulating
safe, fun-filled environment. It symbolizes our conviction that
nurtured roots lay the foundation of a fully grown blossomed
tree.
Health, Wellbeing. Assurance, Right Next Door
State-of-the-art healthcare facilities at New Town DLF
BTM EXTN.
In these years of fast paced lives, your family's wellbeing is
5
foremost in our minds. Our healthcare centre will better the
latest in screening, diagnosis, and medical care with
competent medical professionals by your side, we will
make sure that you would always remain in the best of
health.
Comfort, Confidence, Peace of Mind Right Next Door.
Keeping your loves ones safe and secure at New Town, DLF
BTM EXTN.
Let New Town set your mind at rest when it comes to
security. Our advanced, state-of-the-art security system
ensures comfort & peace of mind for you and your loved
ones, with monitored gates, CCTV for parking and entrance
lobby, video surveillance system and a rigorously screened
24-hour security guard workforce, New Town offers you a
secure and a well-protected abode.” (emphasis supplied)
4 Responding to the representation held out by the developer, the
complainants booked flats in the residential project. The flat buyers entered into
agreements with the developer. Clause 11(a) of the ABA indicated that the
developer would endeavour to complete construction within a period of thirty-six
months from the date of the execution of the agreement save and except for
force majeure conditions. Clause 11(a) provided:
“11. (a) Schedule for Possession of the Said Apartment
The Company/LOC based on the present plans and
estimates and subject to all just exceptions, endeavors to
complete construction of the Said Building /Said Apartment
within a period of thirty six (36) months from the date of
execution of this Agreement unless there shall be delay or
failure due to Force Majeure conditions including but not
limited to reasons mentioned in Clauses 11(b) and 11(c) or
due to failure of Allottee to pay in time the Total Price and
other charges taxes, securities etc. and dues/payments or
any failure on the part of the Allottee to abide by all or any of
the terms and conditions of this Agreement.”
6
5 Force majeure stipulations were illustrated in sub-clauses (b) and (c) of
clause 11, which included delay due to the reasons beyond the control of the
developer and failure to deliver possession due to Government rules, orders or
notifications, respectively. Construction was behind schedule. The flat purchasers
were informed on 12 January 2011 that possession of the apartments was
expected to be completed by the middle of 2012. This assurance was not fulfilled.
By a communication dated 18 June 2013, the developers issued a revised
timeline intimating all flat buyers that the delivery of possession would commence
from October 2013. However, on 8 August 2013 another communication was
issued stating that the real estate industry was affected by an economic slowdown which had hampered the pace of construction. The date for handing over
possession was extended to June 2014. A tentative schedule for delivery was
indicated under which Towers D1 and D2 would be handed over by January
2014, and Towers A3 to A6, A7, B3 and B4 would be handed over by May 2014.
On 8 August 2014, the timelines for handing over possession were again
extended by the developers : under the revised schedule the flats in Towers D1
and D2 were to be handed over in August 2014, those in A1 to A-7 in February
2015, B1 to B6 in April 2015 and C1 to C4 in June 2015. On 4 May 2015, the
developers issued another communication indicating the progress of the work
and informed the purchasers that site visits had been initiated for the project “till
we receive the occupancy certificate for clusters A, B and C”. This is an
admission of the fact that until then the occupation certificate had not been
received. The obligation to handover possession within a period of thirty-six
months was not fulfilled.
7
6 The first batch of nine flat purchasers moved a consumer complaint before
the NCDRC complaining of a breach by the developer of the obligation,
contractually assumed, under the terms of the ABA. Since the nine complainants
purported to represent the entire group of flat purchasers, a notice of the
complaint under Section 12(1)(c) of the Consumer Protection Act 19863 was
published in the newspapers.
7 Numerous applications for impleadment were allowed by the NCDRC and
an amended complaint was ordered to be filed. On the complainants moving an
application under Section 12(1)(c), the NCDRC by its order dated 21 November
2017 permitted them to file the complaint on behalf or for the benefit of all the flat
buyers who were interested in the reliefs. However, flat buyers who had (i)
executed deeds of conveyance; or (ii) executed affidavits while accepting the
agreed compensation in full and final satisfaction; or (iii) received possession
within the stipulated time period; or (iv) had sold their flats after the execution of
the conveyance; or (v) who were subsequent purchasers having purchased the
flat after the execution of the conveyance deed were to remain outside the
purview of the proceedings. Further, the buyers from whom Preferential Location
Charges, charges for the preferential location of the apartment, were not charged
and were not chargeable were to remain out of the class on whose behalf or
benefit the complaint was instituted. On a challenge to the order, this Court by an
3
“CP Act 1986”
8
order dated 10 April 2018 directed:
“Since the complaint filed by the appellants was only by nine
persons jointly for their benefit, the same could not be treated
to be in representative capacity. Accordingly, the impugned
order is set aside.
Aggrieved parties are at liberty to file an appropriate fresh
application under Section 12(1)(c) of the Consumer
Protection Act, 1986 before the National Consumer Disputes
Redressal Commission within two weeks from today. The
same may be disposed of by the National Commission in
accordance with law within three months from the date of
filing of such an application.”
8 Pursuant to the liberty which was granted by this Court, an I.A.
4 was filed
before the NCDRC under Section 12(1)(c). The application was disposed of on
13 July 2018 which led to an appeal before this Court.
9 On 28 September 2018, this Court set aside the order of the NCDRC with
the following directions:
“Having heard learned counsel for the appellants, we are of
the view that the impugned judgment dated 13.07.2018
needs to be set aside. We set it aside and direct the National
Consumer Disputes Redressal Commission to treat the
complaint, as amended, that has been filed, as a complaint
filed on behalf of all 339 persons and to proceed on merits.
It will be open for the respondents to give their say on the
merits of each of the 339 complainants.
The Commission will decide the matter within a period of six
months from today.
The Civil Appeals are disposed of accordingly.”
4
IA No. 8083 of 2013
9
10 Procedural directions issued upon several impleadment applications
resulted in a further order of this Court of 8 May 2019 reiterating that the
complaint would be treated as having been filed on behalf of 339 persons. By its
order dated 28 September 2018, which was reiterated again on 8 May 2019, this
Court had laid down a peremptory time schedule of six months for the disposal of
the complaint. Eventually, on 2 July 2019, the complaint was dismissed by the
NCDRC.
11 Civil Appeal No 6239 of 2019 comprises of 83 appellants. Civil Appeal No
6303 of 2019 comprises of 88 appellants. Thus, there are before this Court a total
of 171 flat purchasers in the appeals. The complaint before the NCDRC, which
was confined by the order of this Court dated 28 September 2018 to 339
complainants, now covers a more restricted field of 171 flat purchasers.
Annexure-1 to Civil Appeal No 6239 of 2019 contains a tabulation of (i) names of
the flat purchasers; (ii) dates on which the flats were booked; (iii) dates on which
the ABAs were signed; (iv) dates by which possession was to be handed over
under the ABAs; and (v) dates on which the letter for possession was issued by
the developers.
12 The NCDRC divided the group of 339 flat buyers into six groups based on
whether or not they had taken possession, executed deeds of conveyance,
settled the dispute or sold the flats before or during the pendency of the
complaint or their applications for impleadment:
10
Group A: Complainants who took possession of their
flats before the filing of the complaint/impleadment
applications.
Group B: Complainants who took possession and
executed deeds of conveyance during the pendency
of the complaint/impleadment applications.
Group C: Complainants who took possession during
the pendency of the complaint/impleadment
applications but have not executed deeds of
conveyance.
Group D: Complainants who settled their dispute
during the pendency of the complaint/ impleadment
applications.
Group E: Complainants who sold their flats during the
pendency of the complaint/impleadment applications.
Group F: Complainants who have not taken
possession of the flats and have not executed a deed
of conveyance.
13 The NCDRC held that flat buyers in Groups A and B who had taken
possession before the filing of the complaint / impleadment applications and
those who took possession and executed deeds of conveyance before or during
the pendency of the proceedings would not be entitled to pursue their claims. The
execution of the deed of conveyance, according to the NCDRC, is a transfer of a
right in property and it is not within the jurisdiction of the Commission to entertain
a grievance that the conveyances have been entered into under coercion.
Additionally, according to NCDRC, under the conveyance deed, such flat buyers
had accorded their satisfaction to the services provided by the developer and
11
voluntarily discharged the developer of all its liabilities under the ABA. As regards
flat purchasers in Group C, the NCDRC noted that even those who have taken
possession but have not executed a deed of conveyance have voluntarily
discharged the developer. The NCDRC observed that flat buyers in Group C had
taken possession without protest, without its permission and without lodging any
complaint with it after taking the possession. Those in Group D who had settled
their dispute during the pendency of the complaint were held to be estopped from
pursuing their grievances. The NCDRC did not accept the contention of the flat
buyers in Group D that that they had settled the matter under coercion and undue
influence since, according to the NCDRC, no specific facts and circumstances
were pleaded by such flat buyers which made them surrender their free will. The
buyers in Group E who have sold their flats during the pendency of the complaint
were held to have no subsisting right. The NCDRC noted that as regards Group F
(complainants who had neither taken possession nor executed a conveyance), as
many as 337 out of 339 flat purchasers had in fact taken possession. The
NCDRC had to deal with the claims of two remaining complainants, who had
accepted the delayed compensation but did not accept possession. Their
complaints were dismissed.
14 The primary grounds on which compensation have been sought before the
NCDRC were:
(i) Delay in handing over possession of the flats;
(ii) Reimbursement of taxes and interest charged to the flat purchasers
under clause 1.10 of the ABA;
12
(iii) Deficiency in providing amenities;
(iv) Levy of electricity charges by the developer; and
(v) Failure to construct the club house.
15 The NCDRC, in the course of its judgment, observed that delay in the
handing over of flats to the flat purchasers was admitted. While recording a
finding of fact that there was an admitted delay on the part of the developer, the
NCDRC held that the agreements provided compensation at the rate of Rs 5 per
square foot of the super area for every month of delay. The NCDRC held that the
flat purchasers who agreed to this stipulation in the agreements were not entitled
to seek any amount in addition. Paragraph 470 of the judgment of the NCDRC
contains its finding:
“470. There is no dispute to the fact that the completion of the
project had been delayed. Delay had been acknowledged by
the opposite parties. They had also offered to these
complainants the delayed compensation calculated @ Rs 5/-
per sq. ft. of the super area.”
The NCDRC observed that the developer had while computing the final demand
made an adjustment on account of delayed compensation at the rate stipulated in
the ABA. The flat purchasers having been provided credit at the rate agreed by
the developers, it was held that no further entitlement existed under the law. In
the view of the NCDRC, the flat purchasers had failed to prove that the stipulation
contained in the agreement for the payment of compensation at Rs 5 per square
foot was unreasonable. In taking this view, the Commission has lent support to its
decision by relying upon the decisions of this Court in DLF Homes Panchkula
13
Pvt. Ltd. v. D S Dhanda, Etc.5
(“Dhanda”) and Ghaziabad Development
Authority v. Balbir Singh6
(“Balbir Singh”). On the merits of the other
grievances, the NCDRC has held that
(i) The charges recovered towards tax and interest are in terms of clause
1.10 of the ABA;
(ii) Charges recovered for electricity are in terms of the ABA;
(iii) The levy of parking charges is valid; and
(iv) The club house has been constructed.
16 In order to facilitate the final disposal of the Civil Appeals, counsel
appearing on behalf of the appellants formulated the nature of the grievances of
the flat buyers in the written submissions tendered during the hearing. Mr
Prashant Bhushan, learned Counsel appearing for the appellants has formulated
his submissions under the following heads:
(i) There is a gross delay ranging between two and four years in handing
over possession and the flat buyers ought not to be constrained by the
terms of the agreement which are one-sided and unreasonable;
(ii) The execution of conveyances or settlement deeds would not operate
to preclude the flat buyers from claiming compensation. The emails of
the developer clearly indicate that the flat buyers were not permitted to
execute conveyances or to receive possession under protest;
(iii) The amenities which have been contracted for have not been provided
5
2019 SCC OnLine SC 689
6
(2004) 5 SCC 65
14
by the developers; and
(iv) The flat buyers are not liable to indemnify the developer for the demand
of interest and penalty raised by the tax authorities as a result of the
failure to deposit the tax on time. During the oral arguments, it was
clarified that only interest has been recovered from the flat buyers.
The above submissions of Mr Prashant Bhushan have been reiterated in the
submissions urged before the Court by Mr Bishwajit Bhattacharya, learned Senior
Counsel appearing on behalf of another group of purchasers. Mr R
Balasubramanian, learned Senior Counsel has, while adopting the submissions
which were urged by Mr Prashant Bhushan, advanced submissions on the levy of
electricity charges and charges for parking spaces.
17 Opposing the submissions which have been urged on behalf of the
appellants, Mr Pinaki Misra, learned Senior Counsel urged that:
(i) Despite the order of this Court dated 28 September 2018, no evidence
has been led by the complainants to discharge the onus placed upon
them to establish coercion or duress while executing conveyances or
settlements;
(ii) Possession of the complex, which is situated on land admeasuring
about 27 acres and comprising of 813 apartments in nineteen towers
has been handed over between four to six years ago and the developer
has transferred his right, title and interest to the Residents‟ Welfare
Association (“RWA”);
15
(iii) The allottees have benefited by the appreciation in the value of their
flats;
(iv) Out of 171 applicants, 145 have received compensation at the agreed
rate while handing over possession. The allotments were escalation
free and the burden of increased costs has been borne by the
developer;
(v) Under clause 14 of the ABA, the flat buyers have been compensated at
the rate of Rs 5 per square foot per month which would work out to
about Rs 7500 per month for a flat admeasuring 1500 square feet. No
proof or measure of actual loss suffered has been adduced;
(vi) The facts pertaining to the appellants would indicate that:
(a) Eighteen appellants executed conveyances before filing the
complaints;
(b) Fifty-four appellants executed conveyances during the course
of the proceedings;
(c) Fifty appellants executed conveyances after the impugned
judgment;
(d) The above individuals include 11 who have entered into
written settlement deeds;
(e) There is no delay in offering possession to seven appellants;
and
(f) Three appellants are continuing to agitate their grievances
despite having transferred their rights in the flats. Out of 171
16
appellants, 122 executed conveyances before the complaint;
during the pendency of the proceedings or thereafter. Eleven
appellants who have entered into settlements did not raise a
ground of coercion prior to a reply which was filed in
December 2018 shortly before the final hearing;
(vii) As regards the construction of facilities and amenities, a club house
containing a swimming pool, gymnasium, tennis court, indoor
badminton court and squash courts has been constructed and an
occupation certificate has been received on 13 May 2019. The RWA is
conscious of the fact that difficulties in the allotment arose as a result of
the action of the Bangalore Development Authority7 which led to the
filing of writ proceedings before the High Court of Karnataka both by the
developer and the RWA. Even after the receipt of the occupation
certificate, the developers have been corresponding with BDA for
permission to hand over possession to the RWA. Other amenities
including a school and health care facilities were going to be developed
in the entire township comprising of 80 acres of which the complex of
27 acres was a part. The flat buyers were aware of the fact that under
the terms of the ABA, the allottees have no right, title or interest in the
amenities outside their residential complex and forming a part of the
wider complex of 80 acres. Moreover, this issue is rendered academic
since the area around DLF township has become urbanized where
adequate facilities are available;
7
“BDA”
17
(viii) Clauses 1.3, 1.10, 2 and 3 require the allottees to bear tax liabilities
including towards works contract tax. When the project commenced in
2009, there was an absence of clarity in regard to the liability on
account of works contract tax which was settled eventually by the
judgment of this Court in Larsen and Toubro Limited v. State of
Karnataka8
. It was as a result of this judgment that the issue was
settled following which, the developer while computing the amount
payable in the final statements of accounts passed on the liability on
account of the interest (but not towards penalty) on a proportionate
basis in terms of clause 1.10 of the ABA;
(ix) Clause 23(b) entitles the developer to raise a demand on a
proportionate basis from the flat buyers for electricity charges. Initially,
BESCOM provided a connection for electricity but subsequently as a
substantial load was required, the developer was permitted to build its
own electricity sub-station. This was built at a cost of Rs. 18.01 crores
for which the pro rata cost could be allocated to flat buyers in terms of
clause 23(b); and
(x) The price of the apartment, as agreed in the ABA, included in the
breakup, parking charges for exclusive use of earmarked parking
spaces. Parking charges were also revealed upfront in the brochure.
The appellants had erroneously relied on the decision of this Court in
Nahalchand Laloochand Private Limited v. Panchali Cooperative
8
(2014) 1 SCC 708
18
Housing Society Limited9
, which turned on the construction of the
provisions of the Maharashtra Apartment Ownership Act 1971 and
Development Control Regulations for Greater Bombay 1991. This has
subsequently been explained in the decision in DLF Limited v.
Manmohan Lowe10
. There is no prohibition in the Karnataka Apartment
Ownership Act upon the developer providing earmarked parking
charges in the breakup of the total price of the apartment.
The rival submissions will now be analysed.
Compensation for delayed possession
18 The fulcrum of the case of the developer rests on clause 14 of the ABA
which is in the following terms:
“14. The Allottee agrees and understands that if the company
is unable to give possession within the period as mentioned
above or such extended period as permitted under this
Agreement, due to reasons other than those mentioned in this
Agreement, then the Company agrees to pay only to the
Allottee and not to anyone else, subject to the Allottee, not
being in default under any terms of this Agreement
compensation @ Rs. 5/- per sq. feet of the Super Area of the
said apartment per month for the period of such Delay. The
adjustment of such compensation shall be done only at the
time of execution of the Conveyance Deed of the Said
Apartment to the Allottee first named under this Agreement
and not, earlier.”
19 Clause 11(a) of the ABA indicates that subject to “all just exceptions” the
developer endeavoured to complete construction within a period of thirty-six
months from the date of the execution of the agreement unless hindered by force
9
(2010) 9 SCC 536
10 (2014) 12 SCC 231
19
majeure conditions. Undoubtedly, the expression „endeavour‟ indicates that the
developer did not bind itself to an inflexible timeline of thirty-six months. But then
again, the timeline of thirty-six moths was subject to just exceptions and could be
excused in the event of force majeure conditions coming into operation. By the
provisions of clause 14, the developer agreed to compensate the flat buyers at
the rate of Rs. 5 per square feet of the super area of the apartment per month for
the period of delay. According to the developer (i) the flat purchasers are bound
by the above stipulations under which their entitlement was to receive
compensation at the agreed rate (and hence not beyond); and (ii) no evidence
has been adduced to indicate that the rate which has been prescribed in the
agreement is unreasonable. The developer relies on the observation in the
decision of this Court in Dhanda11 that when parties have agreed to a
consequence of delay in handing over possession, there must be exceptional
and strong reasons for the consumer fora to award compensation at more than
the agreed rate. In assessing these submissions, we must at the outset note the
submission of Mr Prashant Bhushan, learned Counsel that:
“There are a total of 4 blocks in „WESTEND HEIGHTS‟
project. In Blocks A, B and C, the delay is huge, over 4 years.
For block D, the average delay is 2 years. Out of 339
complainants, for 268, the delay is huge, over 4 years.
The Builder sought repeated extension of time to deliver
possession, vide communications dated 18.06.201312
,
8.8.201313, 8.8.201414, 4.5.201515 etc.”
11 2019 SCC OnLine SC 689
12 Annexure A9 @ page 929
13 Annexure A10 @ page 932, 933
14 Annexure A11 @ page 936
15 Annexure A12 @ page 938
20
20 The extent of the delay as set out in the above submissions has not been
controverted in the submissions which were urged before this Court by the
developer. On the contrary, the finding of the NCDRC in paragraph 470 of its
judgment is that:
“…there is no dispute to the fact that the completion of the
project has been delayed. Delay has been acknowledged by
the opposite parties….”
21 The existence and extent of the delay constitute an admitted factual
position. In fact, in the written submissions which have been filed by the
developer, it has been admitted that out of 171 appellants, 145 were given
compensation in terms of the rate prescribed in clause 14 of the ABA. Once the
developer has accepted that there was a delay on his part which triggered of the
liability to pay compensation (albeit, according to the developer, in terms of
clause 14) there can be no manner of doubt that:
(i) the developer assumed an obligation in terms of the ABA to endeavour to
hand over possession in thirty-six months of the date of the execution of
the agreement;
(ii) there was a failure on the part of the developer to comply with the
contractual obligation;
(iii) the failure of the developer was neither relatable to a “just exception” or the
prevalence of force majeure conditions referable to clause 11; and
(iv) the payment of compensation to the flat buyers or at least 145 of the group
of 171 represents an admission by the developer of its breach, thereby
triggering a liability to pay compensation.
21
22 The only issue which then falls for determination is whether the flat buyers
in these circumstances are constrained by the stipulation contained in clause 14
of ABA providing compensation for delay at the rate of Rs 5 per square feet per
month. In assessing the legal position, it is necessary to record that the ABA is
clearly one-sided. Where a flat purchaser pays the instalments that are due in
terms of the agreement with a delay, clause 39(a) stipulates that the developer
would “at its sole option and discretion” waive a breach by the allottee of failing to
make payments in accordance with the schedule, subject to the condition that the
allottee would be charged interest at the rate of 15 per cent per month for the first
ninety days and thereafter at an additional penal interest of 3 per cent per annum.
In other words, a delay on the part of the flat buyer attracts interest at the rate of
18 per cent per annum beyond ninety days. On the other hand, where a
developer delays in handing over possession the flat buyer is restricted to
receiving interest at Rs 5 per square foot per month under clause 14 (which in the
submission of Mr Prashant Bhushan works out to 1-1.5 per cent interest per
annum). Would the condition which has been prescribed in clause 14 continue to
bind the flat purchaser indefinitely irrespective of the length of the delay? The
agreement stipulates thirty-six months as the date for the handing over of
possession. Evidently, the terms of the agreement have been drafted by the
developer. They do not maintain a level platform as between the developer and
purchaser. The stringency of the terms which bind the purchaser are not mirrored
by the obligations for meeting times lines by the developer. The agreement does
not reflect an even bargain.
22
23 On behalf of the flat purchasers it has been urged by Mr. R
Balasubramanian (a submission which has not been controverted in rejoinder)
that 95 per cent of the purchase price was paid during the course of the first two
and a half to three years. The agreement did not stipulate that the developer
would pay any interest on the amount which had already been received. A large
chunk of the purchase price was thus available to the developer to complete
construction. The court must take a robust and common-sense based approach
by taking judicial notice of the fact that flat purchasers obtain loans and are
required to pay EMIs to financial institutions for servicing their debt. Delays on the
part of the developer in handing over possession postpone the date on which
purchasers will obtain a home. Besides servicing their loans, purchasers have to
finance the expenses of living elsewhere. To postulate that a clause in the
agreement confining the right of the purchaser to receive compensation at the
rate of Rs 5 per square foot per month (Rs 7,500 per month for a flat of 1500
square feet) precludes any other claim would be a manifestly unreasonable
construction of the rights and obligations of the parties. Where there is a delay of
the nature that has taken place in the present case ranging between periods of
two years and four years, the jurisdiction of the consumer forum to award
reasonable compensation cannot be foreclosed by a term of the agreement. The
expression deficiency of services is defined in Section 2 (1) (g) of the CP Act
1986 as:
“(g) "deficiency" means any fault, imperfection, shortcoming
or inadequacy in the quality, nature and manner of
performance which is required to be maintained by or under
any law for the time being in force or has been undertaken to
be performed by a person in pursuance of a contract or
23
otherwise in relation to any service”
24 A failure of the developer to comply with the contractual obligation to
provide the flat to a flat purchaser within a contractually stipulated period
amounts to a deficiency. There is a fault, shortcoming or inadequacy in the nature
and manner of performance which has been undertaken to be performed in
pursuance of the contract in relation to the service. The expression „service‟ in
Section 2 (1) (o) means a service of any description which is made available to
potential users including the provision of facilities in connection with (among other
things) housing construction. Under Section 14(1)(e), the jurisdiction of the
consumer forum extends to directing the opposite party inter alia to remove the
deficiency in the service in question. Intrinsic to the jurisdiction which has been
conferred to direct the removal of a deficiency in service is the provision of
compensation as a measure of restitution to a flat buyer for the delay which has
been occasioned by the developer beyond the period within which possession
was to be handed over to the purchaser. Flat purchasers suffer agony and
harassment, as a result of the default of the developer. Flat purchasers make
legitimate assessments in regard to the future course of their lives based on the
flat which has been purchased being available for use and occupation. These
legitimate expectations are belied when the developer as in the present case is
guilty of a delay of years in the fulfilment of a contractual obligation. To uphold
the contention of the developer that the flat buyer is constrained by the terms of
the agreed rate irrespective of the nature or extent of delay would result in a
miscarriage of justice. Undoubtedly, as this court held in Dhanda, courts
ordinarily would hold parties down to a contractual bargain. Equally the court
cannot be oblivious to the one-sided nature of ABAs which are drafted by and to
24
protect the interest of the developer. Parliament consciously designed remedies
in the CP Act 1986 to protect consumers. Where, as in the present case, there
has been a gross delay in the handing over of possession beyond the
contractually stipulated debt, we are clearly of the view that the jurisdiction of the
consumer forum to award just and reasonable compensation as an incident of its
power to direct the removal of a deficiency in service is not constrained by the
terms of a rate which is prescribed in an unfair bargain.
25 Numerous judgments of this Court have elaborated on the nature and
extent of the jurisdiction of the consumer forum to award just and reasonable
compensation. Since the decision of this Court in Lucknow Development
Authority v. M K Gupta16
, it has been a settled principle of law that the
jurisdiction of the consumer forum extends to the award of compensation to
alleviate the harassment and agony to a consumer. In Balbir Singh17
, a two
judge Bench of this Court, while explaining the ambit of the jurisdiction of the
adjudicatory fora under the CP Act 1986 observed:
“6…The word compensation is of a very wide connotation. It
may constitute actual loss or expected loss and may extend
to compensation for physical, mental or even emotional
suffering, insult or injury or loss. The provisions of the
Consumer Protection Act enable a consumer to claim and
empower the Commission to redress any injustice done. “
26 The court observed that the award of compensation has to be based on a
finding of loss or injury and must correlate to it. The court observed that no “hard
and fast rule” could be prescribed:
16 (1994) 1 SCC 243
17 (2004) 5 SCC 65
25
“8…No hard-and-fast rule can be laid down, however, a few
examples would be where an allotment is made, price is
received/paid but possession is not given within the period set
out in the brochure. The Commission/Forum would then need
to determine the loss. Loss could be determined on basis of
loss of rent which could have been earned if possession was
given and the premises let out or if the consumer has had to
stay in rented premises then on basis of rent actually paid by
him. Along with recompensing the loss the
Commission/Forum may also compensate for
harassment/injury, both mental and physical. “
Where possession has been given, one of the circumstances which must be
factored in is that the purchaser has been compensated by the increase in the
value of the property.
27 In R V Prasannakumaar v. Mantri Castles Pvt Ltd18 under the terms of
the ABA, possession of the flats was to be handed over to the buyers on 31
January 2014. However, the developer received an occupation certificate only on
10 February 2016 and it was thereafter from May 2016 that the developer started
issuing letters offering possession. Based on this, the NCDRC awarded
compensation in the form of interest at the rate of 6 per cent per annum. The
developer had pleaded that since the agreement provided compensation at the
rate of Rs. 3 per square foot per month for delayed possession, the purchasers
were not entitled to anything in addition. Dealing with the submission, this Court
observed:
“9. We are in agreement with the view of the NCDRC that the
rate which has been stipulated by the developer, of
compensation at the rate of 3 per sq. ft. per month does not
provide just or reasonable recompense to a flat buyer who
18 2019 SCC OnLine SC 224
26
has invested money and has not been handed over
possession as on the stipulated date of 31 January 2014. To
take a simple illustration, a flat buyer with an agreement of a
flat admeasuring a 1000 sq. ft. would receive, under the
agreement, not more than Rs. 3000/- per month. This in a city
such as Bangalore does not provide just or adequate
compensation. The jurisdiction of the NCDRC to award just
compensation under the provisions of the Consumer
Protection Act, 1986 cannot in the circumstances be
constrained by the terms of the agreement. The agreement in
its view is one sided and does not provide sufficient
recompense to the flat purchasers.”
The Court observed that there was a delay of two years and hence the award of
interest at the rate of 6 per cent was reasonable and justified.
28 In Pioneer Urban Land and Infrastructure Limited v. Govindan
Raghavan19, there was a delay of almost two years in obtaining an occupancy
certificate after the date stipulated in the ABA. As a consequence, there was a
failure to provide possession of the flat to the purchaser within a reasonable
period. This Court dwelt on the terms of the ABA under which the builder was
entitled to charge interest at 18 per cent per annum for the delay in payment of
instalments by the purchaser. On the other hand, the failure to provide
possession on the part of the developer was subject to a grace period of twelve
months followed by a termination notice of ninety days and a further period of
ninety days to the developer to effect a refund. Adverting to these clauses, the
court noted:
“6.4. A perusal of the apartment buyer's agreement dated 8-5-
2012 reveals stark incongruities between the remedies
available to both the parties. For instance, Clause 6.4(ii) of
the agreement entitles the appellant builder to charge interest
19 (2019) 5 SCC 725
27
@18% p.a. on account of any delay in payment of instalments
from the respondent flat purchaser. Clause 6.4(iii) of the
agreement entitles the appellant builder to cancel the
allotment and terminate the agreement, if any instalment
remains in arrears for more than 30 days. On the other hand,
as per Clause 11.5 of the agreement, if the appellant builder
fails to deliver possession of the apartment within the
stipulated period, the respondent flat purchaser has to wait for
a period of 12 months after the end of the grace period,
before serving a termination notice of 90 days on the
appellant builder, and even thereafter, the appellant builder
gets 90 days to refund only the actual instalment paid by the
respondent flat purchaser, after adjusting the taxes paid,
interest and penalty on delayed payments. In case of any
delay thereafter, the appellant builder is liable to pay interest
@9% p.a. only.
6.5. Another instance is Clause 23.4 of the agreement which
entitles the appellant builder to serve a termination notice
upon the respondent flat purchaser for breach of any
contractual obligation. If the respondent flat purchaser fails to
rectify the default within 30 days of the termination notice,
then the agreement automatically stands cancelled, and the
appellant builder has the right to forfeit the entire amount of
earnest money towards liquidated damages. On the other
hand, as per Clause 11.5(v) of the agreement, if the
respondent flat purchaser fails to exercise his right of
termination within the time limit provided in Clause 11.5, then
he shall not be entitled to terminate the agreement thereafter,
and shall be bound by the provisions of the agreement.”
Justice Indu Malhotra speaking for the Court noted:
“6.8. A term of a contract will not be final and binding if it is
shown that the flat purchasers had no option but to sign on
the dotted line, on a contract framed by the builder. The
contractual terms of the agreement dated 8-5-2012 are ex
facie one-sided, unfair and unreasonable. The incorporation
of such one-sided clauses in an agreement constitutes an
unfair trade practice as per Section 2(1)(r) of the Consumer
Protection Act, 1986 since it adopts unfair methods or
practices for the purpose of selling the flats by the builder.”
The Court observed that in these circumstances, the flat purchasers could not be
compelled to obtain possession which was offered almost two years after the
28
grace period under the agreement had expired. Hence, the NCDRC was held to
have correctly awarded interest at the rate of 10 percent per annum.
29 The decision of this Court in Dhanda20
has been relied upon by learned
Senior Counsel appearing on behalf of the developer as elucidating the principle
that where a flat buyers‟ agreement stipulates a consequence for delayed
possession, exceptional and strong reasons must be established before the
forum constituted under the Act of 1986 awards compensation in addition to what
has been contractually agreed. In Dhanda’s case, the SCDRC issued a direction
for handing over physical possession of the residential unit to the complainant
and for execution of a sale deed. In addition, compensation was awarded by way
of interest at the rate of 12 per cent per annum with effect from twelve months
after the stipulated date under the agreement. In an appeal by the developer, the
NCDRC directed that the rate of interest for a house building loan for the
corresponding period in a scheduled nationalised bank would be appropriate and
if a floating rate of interest was prescribed, the higher rate of interest should be
taken for the computation. A sum of Rs. 1 lac per annum from the date for
handing over possession to the actual date of possession was regarded as
appropriate in the facts of the case. In that case under the terms of the buyer‟s
agreements, possession was to be delivered within twenty-four months of the
execution of the agreement i.e. 10 February 2013 – failing which the developer
was liable to pay compensation at the rate of Rs. 10 per square foot per month
for the delay. The developer contended that construction activities were delayed
as a result of an injunction granted by this Court over a period of eight months
20 2019 SCC OnLine SC 689
29
and consequently sought an extension of the period for handing over possession
by one year. Alternatively, the developer offered to refund the money deposited
with interest at 9 per cent per annum. Construction of 258 independent floors was
completed while about 1,500 units were nearing completion. In two sets of Civil
Appeals which came up before this Court earlier, agreed terms were arrived at
providing for the award of interest at 9 per cent per annum from the date of
deposit till refund. While considering the order of the NCDRC, this Court
observed:
“16. The District Forum under the Consumer Protection Act,
1986 is empowered inter-alia to order the opposite party to
pay such amount as may be awarded as compensation to the
consumer for any loss or injury suffered by the consumer due
to the negligence of the opposite party including to grant
punitive damages. But the forums under the Act cannot award
interest and/or compensation by applying rule of thumb. The
order to grant interest at the maximum of rate of interest
charged by nationalised bank for advancing home loan is
arbitrary and no nexus with the default committed. The
appellant has agreed to deliver constructed flats. For delay in
handing over possession, the consumer is entitled to the
consequences agreed at the time of executing buyer's
agreement. There cannot be multiple heads to grant of
damages and interest when the parties have agreed for
payment of damages at the rate of Rs. 10/- per sq. ft. per
month. Once the parties agreed for a particular consequence
of delay in handing over of possession then, there has to be
exceptional and strong reasons for the SCDRC/NCDRC to
award compensation at more than the agreed rate.”
30 The orders of the SCDRC and NCDRC were held to be without any
foundation being led by the complainant and based purely on a “rule of thumb”.
The court noted that the amount of interest represents compensation to the
beneficiaries who are deprived of the use of the investment which has been
made and will take into its ambit the consequence of a delay in not handing over
30
possession. The court held that both the SCDRC and NCDRC awarded
compensation under different heads on account of a singular default of not
handing over possession. This was held not to be sustainable. The court held
that:
“19. Thus, we find that the complainant is entitled to interest
from the Appellant for not handing over possession as
projected as is offered by it but it is not a case to award
special punitive damages as one of the causes for late
delivery of possession was beyond the control of the
Appellant. Therefore, in view of the settlement proposal
submitted by the Appellant in earlier two set of appeals in
respect of same project, and to settle any further controversy,
the Appellant is directed as follows:
i) To send a copy of the occupation certificate to the
Complainants along with offer of possession. The Appellant
shall also direct the Jones Lang LaSalle - the real estate
maintenance agency, engaged by the Appellant to undertake
such maintenance works as is necessary on account of
damage due to non-occupation of the flats after construction
etc.
ii) It shall be open to the Complainants to seek the assistance of
the maintenance agency to attend to the maintenance work
which may arise on account of non-occupation or on account
of natural vagaries.
iii) Such maintenance work shall be completed by the Appellant
within two months of the offer of possession but the payment
of interest at the rate of 9 per cent per annum will be for a
period of two months from the date of offer of possession in
all situations.
v) Since the Complainants have been forced to invoke
jurisdiction of the consumer forums, they shall be entitled to
consolidated amount of Rs. 50,000/- in each complaint on all
accounts such as mental agony and litigation expenses etc.
The complainant shall not be entitled to any other amount
over and above the amount mentioned above.
vi) In case, the original allottee has transferred the flat, the
transferee shall be entitled to interest at the rate of 9 per cent
per annum from the date of expiry of three years from the
agreement or from the date of transfer, whichever is later.”
31
31 The judgment in Dhanda’s case does not prescribe an absolute embargo
on the award of compensation beyond the rate stipulated in the flat buyers‟
agreement where handing over of the possession of a flat has been delayed.
Dhanda’s case was preceded by consent terms which were presented before
this Court in two earlier civil appeals under which interest at the rate of 9 per cent
had been granted. The decision lays down that the award of interest cannot be
arbitrary and without nexus to the default which has been committed. Hence, the
award of interest at the maximum rate of interest charged by a nationalised bank
for advancing home loans was construed to be arbitrary. It was in this context
that the court observed that the parties having agreed to a consequence for
delay, exceptional and strong reasons must exist for the consumer fora to depart
from the agreed rate. The decision, in other words, does not lay down that there
is an absence of jurisdiction in the adjudicatory fora constituted under the CP Act
1986 to award remedial compensation to a flat buyer for the delay of the
developer in handing over possession on the agreed date.
32 In the present case, there exist, clear and valid reasons for not holding
down the flat buying consumers merely to the entitlement to receive
compensation at the rate of 5 per square foot per month in terms of clause 14 of
the ABA:
(i) There has been a breach on the part of the developer in complying with
the contractual obligation to hand over possession of the flats within a
period of thirty-six months of the date of the agreement as stipulated in
clause 11(a);
32
(ii) The failure of the developer to hand over possession within the
contractually stipulated period amounts to a deficiency of service within
the meaning of Section 2 (1) (g), warranting the invocation of the
jurisdiction vested in the NCDRC to issue a direction for the removal of
the deficiency in service;
(iii) The triggering of an obligation to pay compensation on the existence of
delay in handing over possession is admitted by the developer for, even
according to it, it has adjusted compensation at the agreed rate of Rs 5
per square foot per month to 145 out of the 171 appellants;
(iv) The agreement is manifestly one-sided: the rights provided to the
developer for a default on the part of the home buyer are not placed on
an equal platform with the contractual right provided to the home buyer
in the case of a default by the developer;
(v) There has been a gross delay on the part of the developer in
completing construction ranging between two and four years. Despite
successive extensions of time to deliver possession sought by the
developer, possession was not delivered on time;
(vi) The nature and quantum of the delay on the part of the developer are of
such a nature that the measure of compensation which is provided in
clause 14 of the ABA would not provide sufficient recompense to the
purchasers; and
(vii) Judicial notice ought to be taken of the fact that a flat purchaser who is
left in the lurch as a result of the failure of the developer to provide
33
possession within the contractually stipulated date suffers
consequences in terms of agony and hardship, not the least of which is
financial in nature. Having paid a substantial amount of the purchase
price to the developer and being required to service the debt towards
loan installments the purchaser is unable to obtain timely possession of
the flat which is the subject matter of the ABA.
But, it has been submitted by the developer – a submission which found
acceptance by the NCDRC – that the execution of the Deed of Conveyance by a
flat purchaser precludes a consumer claim being raised for delayed possession.
During the course of the proceedings before the NCDRC, the flat purchasers
relied upon the communications which were issued by the developer to
demonstrate that the purchasers were not permitted by the developer to execute
a Deed of Conveyance or to take possession under protest. The material which
was produced before the NCDRC supports this submission, which was urged
before the Court by Mr Prashant Bhushan, learned Counsel. By a communication
dated 16 February 2016, the developer informed a flat buyer that in terms of the
ABA, the allottee is required to take possession of the apartment by making
payments and executing documentation after the developer has obtained a
certificate for occupation from the competent authority and has offered
possession of the apartment to the allottee. The developer stated:
“We may also like to bring to your notice, that if the
acceptance of offer of possession terms is being conveyed by
the allottee under protest the Company will not be in a
position to hand over the possession and execute the
Conveyance Deed and as such your request to take over the
34
possession and execute the documents under protest is
untenable.”
33 By an email dated 24 December 2016, another flat buyer was informed
that:
“It would be a pleasure to progress with possession once you
submit the affidavit. However we can't accept any documents
to this effect under protest or claim of coercion. This affidavit
has to be unconditionally submitted and possession taken.”
By another communication dated 21 December 2016, a flat purchaser was
informed that:
“It was explained to you in our FDN itself and our earlier
reply/clarifications, that any kind of protest 'is not tenable if
you wish to take possession and register the property as well.
Kindly execute the affidavit as advised and proceed for further
process on registering the property.”
By a communication dated 1 December 2016, the developer informed a flat
purchaser that
“Your letter that you took possession and executed the
documents under protest is untenable and unacceptable and
the company will not be in a position to execute the
conveyance deed under protest.”
Copies of these communications are marked as Annexures P-28, P-29, P-30 and
P-31 to Civil Appeal 6239 of 2019.
34 The developer has not disputed these communications. Though these are
four communications issued by the developer, the appellants submitted that they
35
are not isolated aberrations but fit into a pattern. The developer does not state
that it was willing to offer the flat purchasers possession of their flats and the right
to execute conveyance of the flats while reserving their claim for compensation
for delay. On the contrary, the tenor of the communications indicates that while
executing the Deeds of Conveyance, the flat buyers were informed that no form
of protest or reservation would be acceptable. The flat buyers were essentially
presented with an unfair choice of either retaining their right to pursue their claims
(in which event they would not get possession or title in the meantime) or to
forsake the claims in order to perfect their title to the flats for which they had paid
valuable consideration. In this backdrop, the simple question which we need to
address is whether a flat buyer who seeks to espouse a claim against the
developer for delayed possession can as a consequence of doing so be
compelled to defer the right to obtain a conveyance to perfect their title. It would,
in our view, be manifestly unreasonable to expect that in order to pursue a claim
for compensation for delayed handing over of possession, the purchaser must
indefinitely defer obtaining a conveyance of the premises purchased or, if they
seek to obtain a Deed of Conveyance to forsake the right to claim compensation.
This basically is a position which the NCDRC has espoused. We cannot
countenance that view.
35 The flat purchasers invested hard earned money. It is only reasonable to
presume that the next logical step is for the purchaser to perfect the title to the
premises which have been allotted under the terms of the ABA. But the
submission of the developer is that the purchaser forsakes the remedy before the
36
consumer forum by seeking a Deed of Conveyance. To accept such a
construction would lead to an absurd consequence of requiring the purchaser
either to abandon a just claim as a condition for obtaining the conveyance or to
indefinitely delay the execution of the Deed of Conveyance pending protracted
consumer litigation.
36 It has been urged by the learned counsel of the developer that a
consequence of the execution of the Deed of Conveyance in the present case is
that the same ceases to be a transaction in the nature of “supply of services”
covered under the CP Act 1986 and becomes a mere sale of immovable property
which is not amenable to the jurisdiction of Consumer Fora. In Narne
Construction (P) Ltd. v. Union of India21
, this Court distinguished between a
simple transfer of a piece of immovable property and housing construction or
building activity carried out by a private or statutory body falling in the category of
„service‟ within the meaning of Section 2 (1) (o) of the CP Act 1986. This Court
held that:
“8. Having regard to the nature of transaction between the
appellant Company and its customers involved much more
than a simple transfer of a piece of immovable property it is
clear the same constitutes “service” within the meaning of the
Act. It was not the case that the appellant Company was
selling the given property with all its advantages and/or
disadvantages on “as is where is” basis, as was the position
in UT Chandigarh Admn v. Amarjeet Singh. It is a case where
a clear-cut assurance was made to the purchasers as to the
nature and extent of development that would be carried out
by the appellant Company as a part of package under which
a sale of fully developed plots with assured facilities was
made in favour of the purchasers for valuable consideration.
To the extent the transfer of site with developments in the
manner and to the extent indicated earlier was a part of the
21 (2012) 5 SCC 359
37
transaction, the appellant Company has indeed undertaken to
provide a service. Any deficiency or defect in such service
would make it accountable before the competent Consumer
Forum at the instance of consumers like the respondents.”
The developer in the present case has undertaken to provide a service in the
nature of developing residential flats with certain amenities and remains
amenable to the jurisdiction of the Consumer Fora. Consequently, we are unable
to subscribe to the view of the NCDRC that flat purchasers who obtained
possession or executed Deeds of Conveyance have lost their right to make a
claim for compensation for the delayed handing over of the flats.
37 However, the cases of the eleven purchasers who entered into specific
settlement deeds with the developers have to be segregated. In the case of these
eleven persons, we are of the view that it would be appropriate if their cases are
excluded from the purview of the present order. These eleven flat purchasers
having entered into specific deeds of settlement, it would be only appropriate and
proper if they are held down to the terms of the bargain. We are not inclined to
accept the contention of the learned counsel of the appellants, Mr. Prashant
Bhushan, that the settlement deeds were executed under coercion or undue
influence since no specific material has been produced on record to demonstrate
the same.
38 Similarly, the three appellants who have transferred their title, right and
interest in the apartments would not be entitled to the benefit of the present order
since they have sold their interest in the apartments to third parties. The written
38
submissions which have been filed before this Court indicate that “the two buyers
stepped into the shoes of the first buyers” as a result of the assignment of rights
and liabilities by the first buyer in favour of the second buyer. In HUDA v. Raje
Ram22
, this Court while holding that a claim of compensation for delayed
possession by subsequent transferees is unsustainable, observed that:
“7. Respondents in the three appeals are not the original
allottees. They are re-allottees to whom re-allotment was
made by the appellant in the years 1994, 1997 and 1996
respectively. They were aware, when the plots were reallotted to them, that there was delay (either in forming the
layout itself or delay in delivering the allotted plot on account
of encroachment etc). In spite of it, they took re-allotment.
Their cases cannot be compared to cases of original allottees
who were made to wait for a decade or more for delivery and
thus put to mental agony and harassment. They were aware
that time for performance was not stipulated as the essence
of the contract and the original allottees had accepted the
delay.”
Even if the three appellants who had transferred their interest in the apartments
had continued to agitate on the issue of delay of possession, we are not inclined
to accept the submission that the subsequent transferees can step into the shoes
of the original buyer for the purpose of benefiting from this order. The subsequent
transferees in spite of being aware of the delay in delivery of possession the flats,
had purchased the interest in the apartments from the original buyers. Further, it
cannot be said that the subsequent transferees suffered any agony and
harassment comparable to that of the first buyers, as a result of the delay in the
delivery of possession in order to be entitled to compensation.
22 (2008) 17 SCC 407
39
Amenities
39 The brochure that was issued by the developers spoke of a “Distinctive
DLF Living” while advertising the project, which was described as “DLF Westend
Heights”, New Town. This was described as “the premier choice for Bangalore
living…a premium residential enclave featuring spacious apartments with a rich
selection of amenities.” Westend Heights at New Town was described as a
project which was being developed on a land area of 27.5 acres. The brochure
specifically referred to the amenities being provided. Among them were (i) “The
most exclusive club in Bangalore”; (ii) a swimming pool; (iii) gymnasium/ aerobics
centre; and (iv) a restaurant and Bar together with other sports facilities. Besides
this, the brochure contained a representation of the setting up of a convenience
shopping centre with an array of outlets, a renowned early - learning school and
state of the art health care facilities. Clause 1.10(a) of the ABA, which imposes
the liability to bear taxes on the allottees states that this liability will be
proportionate to the ratio of the super area of the apartment to the total super
area of all the apartments and other “shops, clubs etc” in the said complex.
The grievance in regard to the alleged failure of the developer to provide
amenities may be divided into two segments:
(i) The club house; and
(ii) Other amenities
Club house
40 The developer has stated before the court that a club house containing
appurtenant facilities including a swimming pool, gymnasium, billiards room,
40
tennis court, indoor badminton court, squash court and community hall has been
fully constructed and an occupation certificate has been received on 13 May
2019. The developer has stated that under the building regulations, it has to
handover 5 per cent of the area of the group housing complex to BDA as a civic
amenities (“CA”) area. The RWA has to apply to BDA for allotment of the CA
area in its favour. Upon allotment, the RWA hands over the area to the builder for
construction of the club. The developer relinquished the CA area in favour of the
BDA, constituted an RWA and applied to BDA on 22 June 2010 for the allotment
of the CA site in favour of the RWA. The written submissions indicate that a
dispute over the charges demanded by BDA towards lease rent led to a writ
petition before the Karnataka High Court being instituted both by the developer
and the RWA which was allowed on 29 June 2015. The developer submitted a
building plan to the municipal body. A second writ petition had to be filed in which
the High Court on 18 October 2016 directed the municipal body to proceed with
the approval of the building plans. Sanction for the building plan was received on
18 May 2017 and after construction of the club building, an occupation certificate
was received on 13 May 2019. The developer has stated that it has been
following up with BDA to permit them to hand over possession and management
of the club to the RWA. Since permission of BDA has still not been received legal
action is contemplated again. The developer has produced photographs depicting
the amenities which have been provided within the precincts of the club house.
Membership fees for the club are stated to have been received in the account of
the RWA and not in the account of the developer. The position which has been
stated before the court as elucidated above has not been disputed by counsel for
41
the appellants. Hence, we find that there has been no breach by the developer of
the obligation to provide a constructed facility of a club for the RWA.
Other amenities
41 As regards the other amenities, the defence of the developer is that these
were to be developed as an integral element of the entire township of 80 acres of
which the project admeasuring 27 acres (comprised in Westend Heights) was a
part. The ABA stipulates that allottees of the complex have no right, title and
interest in respect of the amenities or facilities outside the residential complex,
which lie within the larger township. According to the developer, no part of the
consideration which was paid by allottees, including the appellants, was towards
the amenities and facilities falling outside the boundary of the complex. In this
regard, the developer relies on the following stipulation accepted by allottees
under clause 5 of the Booking Application Form:
“The applicant confirms and represents that he has not
made any payment to the Company in any manner
whatsoever and that the Company has not indicated /
premised / represented / given any impression of any kind in
an explicit or implicit manner whatsoever, that the Applicant
shall have any right, title or interest of any in whatsoever in
any lands, buildings, common areas, facilities and amenities
failing outside the Said Complex…”
The above stipulation is reiterated under clause 1.21 of the ABA:
“The allottee acknowledges and confirms that the allottee is
not entitled to or has not paid for the lands outside the said
land/said complex whether the same is within said project or
other. The said project would comprise of many complexes
similar on different to said complex. Allottee has not paid any
amount towards any other lands, areas, facilities and
amenities including but not limited to those listed below, and
42
as such, the allottee shall have no right interest of any nature
whatsoever in the same and the same are specifically
excluded from the scope of this agreement. The allottee
acknowledges that the ownership of such land and facilities
and amenities shall vest solely with the company/LDC and its
associate companies subsidiaries and they alone shall have
sole right and absolute authority to deal with the same
including their usage and manner/method of use, disposal
etc. creation of rights in favour of other person by way of sale,
transfer, lease Joint venture, collaboration or any other
including transfer of government, semi-government, any other
person. "
42 Now, it is correct as the developer contends that the flat purchasers have
no right, title or interest in respect of the amenities which were to be constructed
by the developer as a part of the larger township of New Town. The entire area
comprised 80 acres of which Westend Heights was situated on 27 acres. The
absence of a title or interest in the flat purchasers in the amenities to be provided
outside the area of 27 acres begs the question as to whether there was a breach
of a clear representation which was held out to the flat purchasers by the
developer. A deficiency under Section 2(1)(g) means a fault, imperfection,
shortcoming or inadequacy in the quality, nature and manner of performance.
This may be required to be maintained under law or may be undertaken to be
performed in pursuance of a contract or otherwise in relation to any service. The
builder invited prospective flat purchasers to invest in the project of Westend
Heights on the basis of a clear representation that the surrounding area of New
Town situated on 80 acres was being developed to provide a wide range of
amenities including a shopping centre, health care facilities and an early learning
school. The developer has failed to provide these amenities. In the reply, the
developer has stated that:
43
“It is stated that School, Commercial Complex and Health
clinic are part of the facility which will be provided upon the
completion of the Whole New Town project as these facilities,
with existing population cannot sustain these facilities. Every
matter has to be adjudicated in light of its own facts and
circumstance…”
In the written submissions of the developer, the failure to provide the amenities is
sought to be glossed over by contending that:
“…the issue of these facilities has since become completely
academic since the area around the DLF Township has
already become totally urbanized and well developed thanks
in larger measure due to the DLF‟s activities in the area and
there are now many proximate hospitals, schools, shopping
areas that have mushroomed in the immediate vicinity and
neighbourhood of the DLF Township which are in fact being
regularly and conveniently used by the residents of the DLF
residential complex which include the Appellants herein. As
such, there is no loss or claim for any damages that could be
said to have accrued to the Appellants either under the ABA
or otherwise under this alleged head of claim.”
43 In other words, what the developer holds out as a defence is that though
there has been a failure on their part to provide the amenities, the flat buyers
have the benefit of facilities in the surrounding area which has become
urbanised. We cannot agree with this line of submissions. The reply of the
developer seeks to explain the failure to construct the facilities on the ground that
the “existing population cannot sustain these facilities” – a school, commercial
complex and health care facilities. This is a case involving an experienced
developer who knew the nature of the representation which was being held out to
the flat purchasers. Developers sell dreams to home buyers. Implicit in their
representations is that the facilities which will be developed by the developer will
provide convenience of living and a certain lifestyle based on the existence of
44
those amenities. Having sold the flats, the developer may find it economically
unviable to provide the amenities. The flat purchasers cannot be left in the lurch
or, as in the present case, be told that the absence of facilities which were to be
provided by the developer is compensated by other amenities which are available
in the area. The developer must be held accountable to its representation. A flat
purchaser who invests in a flat does so on an assessment of its potential. The
amenities which the builder has committed to provide impinge on the quality of
life for the families of purchasers and the potential for appreciation in the value of
the flat. The representation held out by the developer cannot be dismissed as
chaff. True, in a situation such as the present it may be difficult for the court to
quantify the exact nature of the compensation that should be provided to the flat
buyers. The general appreciation in land values results in an increase in the
value of the investment made by the buyers. Difficulties in determining the
measure of compensation cannot however dilute the liability to pay. A developer
who has breached a clear representation which has been made to the buyers of
the amenities which will be provided to them should be held accountable to the
process of law. To allow the developer to escape their obligation would put a
premium on false assurances and representations made to the flat purchasers.
Hence, in factoring in the compensation which should be provided to the flat
buyers who are concerned in the present batch of appeals, we would necessarily
have to bear this issue in mind.
Tax
44 The ABA contained specific provisions in regard to the payment of taxes.
45
Clause 1.3 of the ABA provided:
“1.3 The Allottee shall make the payment of the Total price as
per the payment plan set out in annexure -III of this
Agreement. Other charges, securities, payments etc. (as
specified in this Agreement), Taxes and increase thereof (as
provided in clause 1.10) shall be payable by the Allottee, as
and when demanded by the Company.”
Clause 1.10 contained a specific provision in regard to the obligation of the
allottee to pay taxes in addition to the total price. Clause 1.10 provided:
“1.10. The Allottee agrees and understands that in addition to
Total price, the Allottee shall be liable to pay the Taxes, which
shall be charged and paid as under:
a) A sum equivalent to the proportionate share of Taxes shall
be paid by the Allottee to the Company. The Proportionate
share shall be the ratio of the Super Area of the said
Apartment to the total super area of all the apartments other
buildings shop, club etc. in the said complex.
b) The Company shall periodically intimate to the Allottee
herein, on the basis of certificates from a Chartered Engineer
and /or a Chartered· Accountant, the amount payable as
stated above which shall be final and binding on the Allottee
and the Allottee shall make payment of such amount within
30 (thirty days) of such intimation.”
The ABA also contains the following provisions:
“2. Payment for taxes on land, wealth-tax, cesses etc. by
Allottee: -
The Allottee agrees and confirms to pay all Government
rates, tax on land, municipal tax, property taxes, wealth
tax, Building and Other Construction Workers Welfare
Fund (Cess),taxes, one time building tax, luxury tax if any,
fees or levies of all and any kind by whatever name
called, whether levied or Leviable now or in future by the
Government or municipal authority or any other
governmental authority on the Said Complex and I or the
Said Building or land appurtenant thereto as the case
46
may be as assessable or applicable from the date of the
Application if the Said Apartment is assessed separately
and if the Said Apartment is not assessed separately then
the Allottee shall pay directly to the concerned authority
and if the same is levied on or paid by the Company or
the Allottee then the same shall be borne and paid by the
Allottee on pro-rata basis and such determination of
proportionate share by the Company and demand shall
be final and binding on the Allottee. However, if the Said
Apartment is assessed separately the Allottee shall pay
directly to the Government Authority.
3. Amount paid by Allottee with Application
The Allottee has paid a sum of Rs. 3,00,000/- (Rupees 3
Lakhs only) alongwith the Application, the receipt of
which the Company doth hereby acknowledge and the
Allottee agrees to pay the remaining price of the Said
Apartment as prescribed in schedule of payments
(Annexure-III) attached with this Agreement along with all
other charges, Taxes, securities etc. as mentioned in this
Agreement and as per the de-mand raised by the
Company in accordance with the Agreement.”
The ABA contains the definition of taxes in the following terms:
“"Taxes" shall mean any and all taxes payable by the
Company/LOC and/or its contractors, suppliers, consultants,
etc. by way of value added tax (VAT), state sales tax, central
sales tax, works contract tax, service tax, cess, levies and
educational cess and any other taxes levies, charges by
whatever name called levied and collected by Government
Agency in connection with Development / construction of the
Said Apartment/Said Building/Said Complex.”
The expression total price is also defined in the ABA so as to be exclusive inter
alia of taxes.
45 The two certificates of the Chartered Accountant issued on 26 July 2013
and 9 August 2014 indicate that taxes inclusive of interest have been recovered.
According to the appellants, the builder admitted that it had “not properly
47
discharged” his liability towards taxes for a period of thirty-six months between
2011-2012 and 2013-2014 and that tax dues were paid on 25 March 2015
together with penalty and interest. Hence, it has been urged that the liability to
pay interest which arose on account of the default of the developer in discharging
the tax liability on time cannot be fastened upon the buyers.
46 On behalf of the developer it has been submitted that when construction
commenced in 2009, there was an absence of clarity on whether works contract
tax was liable to be paid in relation to agreements between owners-developers
and allottees of apartments where the apartments were to be delivered in future.
In 2013, this Court delivered its judgment in Larsen and Toubro Limited v State
of Karnataka23 as a result of which the liability towards works contract tax was
adjudicated upon. Consequently, while computing the amount payable in the final
statements of accounts, the developer passed on the interest burden but not the
penalty on a proportionate basis in terms of clause 1.10. The allottees were
required to pay their proportionate share of the works contract tax in terms of the
ABA and the final demand was raised at the time of the offer of possession.
47 The specific conditions contained in the ABA clearly imposed the liability to
bear the proportionate share of taxes on the purchasers. Clauses 1.3 and 1.10
leave no manner of doubt in regard to the position. The developer has offered an
explanation of why as a result of pending litigation, the dues towards works
contract tax were not paid earlier. Indeed, if they were paid earlier, the
purchasers would have been required to reimburse their proportionate share of
23 (2014) 1 SCC 708
48
taxes earlier as well. No part of the penalty imposed on the developer has been
passed on to the purchasers. In view of the terms of the ABA and the explanation
which has been submitted by the developer, there is no deficiency of service in
regard to the demand of interest payable on the tax which was required to be
deposited with the revenue.
Electricity
48 The submission by Mr. R. Balasubramanian, learned Senior Counsel is
that the initial collection of Rs. 1.50 lacs from each buyer towards BESCOM
/BWSSB charges for electricity and water are admitted. Subsequently, invoking
clause 23(b) of the ABA, the developer collected two lacs from each buyer
towards additional electricity charges. The appellants contest the entitlement of
the developer to claim these charges.
Clause 23(b) of the ABA is in the following terms:
“23. (b) Payments and other charges for bulk supply of
electrical energy
If Company or the Maintenance Agency decides to apply for
and thereafter receives permission from BESCOM or from
any other body / commission/ regulator/ licensing authority
constituted by the Government of Karnataka for such
purpose, to receive and distribute bulk supply of electrical
energy in the Said Project/Said Complex then the Allottee
undertakes to pay on demand to the Company proportionate
share as may be determined by the Company of all payments
and charges paid/ payable by the Company or the
Maintenance Agency to BESCOM…The proportionate share
of cost incurred by the Company for creating infrastructure
like HT feeder, EHT sub stations etc shall also be payable by
the Allottee on demand.”
49 According to the developer, initially an electricity connection was provided
49
by BESCOM without insisting on the requirement of an electric sub-station.
Subsequently as occupation certificates were received for additional towers,
BESCOM required a dedicated electric sub-station which was constructed by the
developer at a cost of Rs. 18.01 crores. The pro rata cost for setting up this
additional infrastructure was, according to the developer, payable by the
allottees. When offers for possession were issued to the buyers, the following
stipulation was contained in the letter:
“Our initial effort was to obtain and energize the power supply
to the entire project of 1830 apartments through individual ll
KV feeders from Golahalli 66/llKV Substation. On this basis,
the costing for infrastructure towards provisioning of utilities
as per clause 1.14, 1.15, 23(b) and JDC of ABA was
estimated at rate Rs. 127.96/sft., which was reflected in the
Final Demand to D Block customers. However, after a
detailed evaluation of the load requirement for the project as
per norms, BESCOM has now stipulated that, in accordance
with clause 3.2.4 of KERC Regulations, we establish a
dedicated 66/11 kv Substation within our project site to cater
to the needs of the project, instead of the earlier proposed
scheme of 11 Kv feeders from Golahalli. The increase in cost
because of this new sub-station and allied works, over and
above the originally envisaged 11KV scheme is estimated
@Rs. 18.01 Cr., thereby increasing the total infrastructure
cost recovery towards provisioning of utilities to Rs.
188.00/sft. In view of the above said amounts are being
recovered on the basis of provisional estimates. On
commissioning and energizing the substation, the company
shall arrange a certificate from independent chartered
accountant/ chartered engineer to arrive at the actual cost
incurred. Your share of the said actual cost by the Company
shall be duly intimated to you accordingly. If it is found that
excess amount paid by you, over and above the actual cost
incurred by the company, said excess amount so collected
shall be refunded to you without interest. If the actual
expenses exceeds the estimated amount computed @Rs.
188/-sq. ft. then demand for the shortfall amount shall be
raised through further demand on the owner of the property
and shall be payable by you. We would further like to bring to
your kind attention that the provision of 66/llKV substation will
ensure better quality uninterrupted power supply as
compared with the previously planned scheme of
11KV‟reeders.”
50
50 Mr. R. Balasubramanian, learned Senior Counsel contends that clause
23(b) relates to receiving and distributing the bulk supply of electrical energy to
“the said project /said complex” which is defined as “project under the name and
style of “New Town DLF BTM Extension”. According to the submission, the
charges have been collected for the entire New Town project and not for
Westend Heights alone. In this context it has also been submitted that distribution
of electricity is governed by the KERC Regulations 2006. While planning the
project, the developer calculated the cost of the 66/11 KV sub-station and
collected charges from each of the 1830 buyers. Hence, it has been submitted
that there was no requirement of additional bulk supply of electricity for the
nineteen hundred buyers. In this context, the formulation in the written
submissions is extracted below:
“(under) regulation 3.02 (e) of KERC (Conditions of Supply of
Electricity by the Distribution Licensee) Regulations 2004, it is
mandatory to set up 66 KV supply line/ KV substation if the
demands goes beyond 7500 KVA. Further under regulation
3.2.4 KERC (Recovery of Expenditure for Supply of
Electricity) Regulations 2004 : “In case of layouts/buildings
requiring power supply and the requisitioned load is more
than 7500 KVA, the developer/ Applicant shall provide the
space for erection of sub-station and also bear the entire
charges of such a sub-station and associated
lines/equipments. The work shall be carried out either by the
Licensee duly recovering the charges as per estimate or by
the Applicant himself through appropriate class of licensed
contractor by paying 10% of the estimate as supervision
charges to the Licensee.”
51 The NCDRC has upheld the collection of the charges towards electricity
51
based on the terms of the ABA. There is no infirmity in the finding of the NCDRC,
which is based on the provisions contained in clause 23(b) of the ABA. The
charges recovered are not contrary to what was specified in the contract between
the parties.
Parking
52 The appellants seek a refund of an amount of Rs. 2.25 lacs collected from
each buyer towards car parking. The submission is that under Section 3(f) of the
Karnataka Apartment Ownership Act 197224
, common areas and facilities
include parking areas. According to the appellants, the flat buyers had already
paid for the super area in terms of clause 1.6 of ABA including common areas
and facilities which would be deemed to include car parking under the KAO Act.
The relevant portion of clause 1.6 is extracted below:
“1.6. The Allottee agrees that the Total price of the said
Apartment is calculated on the basis of its Super Area only
(as indicated in clause 1.1.) except the parking space,
additional car parking space which are based on fixed
valuation…."(emphasis supplied)
53 We are unable to accede to the above submission. The ABA contained a
break-up of the total price of the apartment. Parking charges for exclusive use of
earmarked parking spaces were separately included in the break-up. The parking
charges were revealed to the flat buyers in the brochure. The charges recovered
are in terms of the agreement.
54 The decision of this Court in Nahalchand Laloochand Private Limited v.
24 “KAO Act”
52
Panchali Cooperative Housing Society Limited25 turned on the provisions of
the Maharashtra Ownership Flats Act 1971, as explained in the subsequent
decision of this Court in DLF Limited v. Manmohan Lowe26
. The demand of
parking charges is in terms of the ABA and hence it is not possible to accede to
the submission that there was a deficiency of service under this head.
55 For the above reasons we have come to the conclusion that the dismissal
of the complaint by the NCDRC was erroneous. The flat buyers are entitled to
compensation for delayed handing over of possession and for the failure of the
developer to fulfil the representations made to flat buyers in regard to the
provision of amenities. The reasoning of the NCDRC on these facets suffers from
a clear perversity and patent errors of law which have been noticed in the earlier
part of this judgment. Allowing the appeals in part, we set aside the impugned
judgment and order of the NCDRC dated 2 July 2019 dismissing the consumer
complaint. While doing so, we issue the following directions:
(i) Save and except for eleven appellants who entered into specific
settlements with the developer and three appellants who have sold their
right, title and interest under the ABA, the first and second respondents
shall, as a measure of compensation, pay an amount calculated at the
rate of 6 per cent simple interest per annum to each of the appellants.
The amount shall be computed on the total amounts paid towards the
purchase of the respective flats with effect from the date of expiry of
thirty-six months from the execution of the respective ABAs until the
25 (2010) 9 SCC 536
26 (2014) 12 SCC 231
53
date of the offer of possession after the receipt of the occupation
certificate;
(ii) The above amount shall be in addition to the amounts which have been
paid over or credited by the developer at the rate of Rs 5 per square
foot per month at the time of the drawing of final accounts; and
(iii) The amounts due and payable in terms of directions (i) and (ii) above
shall be paid over within a period of one month from the date of this
judgment failing which they shall carry interest at the rate of 9 per cent
per annum until payment.
56 The civil appeals are accordingly allowed in the above terms.
57 Pending application(s), if any, shall stand disposed of.
…….………….…………………...........................J.
[Dr. Dhananjaya Y Chandrachud]
…….…………………………...............................J.
[K M Joseph]
New Delhi;
August 24, 2020.
